Temporary Space Upon reasonable prior notice from Tenant to Landlord, Landlord agrees to provide Tenant with temporary space (the "Temporary Space") on either the second floor of Building A or the second floor of Building B of a size and in a location to be mutually agreed upon by Landlord and Tenant for a period of time commencing no earlier than sixty (60) days from the date of Tenant's notice requesting that the Temporary Space be made available and expiring on the Commencement Date of this Lease. Tenant's occupancy of the Temporary Space shall be subject to all of the terms and conditions of this Lease to the extent appropriate, except that (i) Annual Fixed Rent for the Temporary Space shall be payable at the annual rate equal to the product of (x) $4.00 and (y) the rentable floor area of the Temporary Space, (ii) for the purposes of determining Tenant's payments on account of Landlord's Operating Expenses under Section 2.6 above and Landlord's Tax Expenses under Section 2.7 with respect to the Temporary Space, the "Rentable Floor Area of the Premises" shall be deemed to be the rentable floor area of the Temporary Space and (iii) the Temporary Space shall be delivered to Tenant in its "as is" condition and no improvement allowance or brokerage commission shall be payable with respect thereto. In addition, it is acknowledged and agreed that if Tenant shall elect to lease any Temporary Space hereunder, Tenant shall be occupying such Temporary Space while Landlord is proceeding with components of the Base Building Work in Buildings A and B and accordingly that Tenant shall use and occupy the Temporary Space in such as manner as to minimize any unreasonable interference with Landlord's performance of the Base Building Work. (signatures on next page) EXECUTED as a sealed instrument in two or more counterparts each of which shall be deemed to be an original. WITNESS: LANDLORD: BOSTON PROPERTIES LIMITED PARTNERSHIP By: Boston Properties, Inc., its general partner By: --/s/ Xxxxx RosenName: Xxxxx RosenTitle: Senior Vice President, Development TENANT ATTEST: By: By: /s/ Xxxxx Xxxxx Name: Name: Xxxxx Xxxxx Title: Secretary or Assistant Secretary Title: President or Vice President Hereto duly authorized By: Name: Title: Treasurer or Assistant Treasurer Hereto duly authorized EXHIBIT A DESCRIPTION OF SITE Those certain parcels of land (with the buildings thereon) situated in Bedford, Middlesex County, Massachusetts bounded and described as follows: PARCELS 1 and 2 Two certain parcels of land situated in Bedford, Middlesex County, Massachusetts, shown as Lot 1 and 2 on a plan entitled “Plan of Land in Bedford, Mass." dated March 1, 1962 by Xxxxxxx X. Xxxxxxx, Inc., recorded with Middlesex South District Deeds as Plan No. 487 of 1962 in Book 10022, Page 278, and together bound and described as follows: SOUTHWESTERLY by Xxxxxx Road by three lines measuring respectively two hundred eighty-three and 011100 (283.01) feet, twenty-one and 271100 (21.27) feet and four hundred eighty-three and 43/100 (483.43) feet; thence SOUTHERLY by said Xxxxxx Road by a curved line, one hundred nineteen and361100 (119.36) feet; thence SOUTHEASTERLY SOUTHERLY and SOUTHWESTERLY by said Xxxxxx Road by several lines measuring respectively two hundred ninety-three and 04/100 (293.04) feet, three hundred fifty three and 041100 (353.04) feet and two hundred twenty and 97/100 (220.97) feet; thence NORTHEASTERLY by the parcel marked "Reserved for Town of Bedford" on said plan, sixteen hundred forty-six and 81/100 (1646.81) feet; and thence NORTHWESTERLY by land now or late of The Worcester Corp., by two lines measuring respectively 305.23 feet and 294.24 feet and by land now or late of Xxxxxxx by two lines measuring respectively 170.33 feet and 64.34 feet, to the place of beginning. For Title see Deed recorded with the Middlesex South District Registry of Deeds in Book 12926, Page 233. PARCEL 3 A certain parcel of land situated in said Bedford, shown on a plan of land in Bedford, Mass.Dated June 5, 1961 by Xxxxxxx X. Xxxxxxx, Inc., Registered Land Surveyors, recorded with Middlesex South District Registry of Deeds at the end of Book 9844, bounded and described as follow: SOUTHWESTERLY by Xxxxxx Road, two hundred ninety-eight and 63/100 (298.63) feet; NORTHWESTERLY by land now or formerly of the Worcester Corporation, two hundred nine and 95/100 (209.95) feet; NORTHEASTERLY by land now or formerly of the Worcester Corporation, two hundred fifty and 57/100 (250.57) feet; and SOUTHEASTERLY by land now or formerly of Sinbad Realty Corporation by two lines respectively measuring one hundred seventy and 33/100 (170.33) feet and sixty-four and 341100(64.34) feet. Containing approximately 60,951 square feet of 1.4 acres according to said plan. For Title see Deed from Xxxxx X. Xxxxxxx and Xxxxxxxxx X. Xxxxxxx recorded with the Middlesex South District Registry of Deeds in Book 13539, Page 732. PARCEL 4 All right, title and interest in and to (i) that portion of Xxxxxx Road described in that certain Deed (a) recorded with the Middlesex South District Registry of Deeds in Book 14013, Page 486 and (b) filed with the Middlesex South Registry District of the Land Court as Document No. 599584 as to which Certificate of Title No. 161163 in Registration Book 936, Page 13 was issued; and
Temporary Taking If the whole or any part of the Leased Property (other than the fee) or of Lessee’s interest under this Lease is condemned by any Condemnor for its temporary use or occupancy (which shall mean a period not to exceed two years), this Lease shall not terminate by reason thereof, and Lessee shall continue to pay, in the manner and at the terms herein specified, the full amounts of Base Rent and Additional Charges. In addition, Lessee shall pay Percentage Rent at a rate equal to the average Percentage Rent during the last three (3) preceding Fiscal Years (or if three (3) Fiscal Years shall not have elapsed, the average during the preceding Fiscal Years). Except only to the extent that Lessee may be prevented from so doing pursuant to the terms of the order of the Condemnor, Lessee shall continue to perform and observe all of the other terms, covenants, conditions and obligations hereof on the part of Lessee to be performed and observed, as though such Condemnation had not occurred. In the event of any Condemnation as in this Section 15.6 described, the entire amount of any Award made for such Condemnation allocable to the Term of this Lease, whether paid by way of damages, rent or otherwise, shall be paid to Lessee. Lessee covenants that upon the termination of any such period of temporary use or occupancy it will, at its sole cost and expense (subject to Lessor’s contribution as set forth below), restore the Leased Property as nearly as may be reasonably possible to the condition in which the same was immediately prior to such Condemnation, unless such period of temporary use or occupancy extends beyond the expiration of the Term, in which case Lessee shall not be required to make such restoration. If restoration is required hereunder, Lessor shall contribute to the cost of such restoration that portion of its entire Award that is specifically allocated to such restoration in the judgment or order of the court, if any, and Lessee shall fund the balance of such costs in a manner reasonably satisfactory to Lessor.
Temporary Reduction of Rent If the Property is destroyed or damaged and Landlord or Tenant repairs or restores the Property pursuant to the provisions of this Article Seven, any rent payable during the period of such damage, repair and/or restoration shall be reduced according to the degree, if any, to which Tenant's use of the Property is impaired. However, the reduction shall not exceed the sum of one year's payment of Base Rent, insurance premiums and real property taxes. Except for such possible reduction in Base Rent, insurance premiums and real property taxes, Tenant shall not be entitled to any compensation, reduction, or reimbursement from Landlord as a result of any damage, destruction, repair, or restoration of or to the Property.
Communications Equipment Members of the board of directors or any committee thereof may participate in and act at any meeting of such board or committee through the use of a conference telephone or other communications equipment by means of which all persons participating in the meeting can hear each other, and participation in the meeting pursuant to this section shall constitute presence in person at the meeting.
Tenant’s Equipment Tenant shall provide notice to Landlord prior to moving any heavy machinery, heavy equipment, freight, bulky matter or fixtures (collectively, “Equipment”) into or out of the Building and shall pay to Landlord any costs actually incurred by Landlord in connection therewith. If such Equipment requires special handling, Tenant agrees (a) to employ only persons holding all necessary licenses to perform such work, (b) all work performed in connection therewith shall comply with all applicable Requirements and (c) such work shall be done only during hours designated by Landlord.
Floor Loading Floor loading capacity shall be within building design capacity. Tenant may exceed floor loading capacity with Landlord’s consent, at Landlord’s sole discretion and must, at Tenant’s sole cost and expense, reinforce the floor as required for such excess loading.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
ADJACENT EXCAVATION-SHORING 32. If an excavation shall be made upon land adjacent to the demised premises, or shall be authorized to be made, Tenant shall afford to the person causing or authorized to cause such excavation, license to enter upon the demised premises for the purpose of doing such work as said person shall deem necessary to preserve the wall or the building of which demised premises form a part from injury or damage and to support the same by proper foundations without any claim for damages or indemnity against Owner, or diminution or abatement of rent.
Parking Facilities All parking areas now or hereafter made available by Landlord for use by tenants, including, without limitation, open-air parking, parking decks and parking areas under or within the Building, whether reserved, exclusive, non-exclusive or otherwise.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
