Damage or Destruction Condemnation 16.1. If the Hotel is damaged by fire or other casualty, Operator shall promptly notify Owner. This Agreement shall remain in full force and effect subsequent to such casualty provided that either party may terminate this Agreement upon thirty days’ prior written notice to the other party if (a) Owner shall elect to close the Hotel as a result of such casualty (except on a temporary basis for repairs or restoration) or (b) Owner shall determine in good faith not to proceed with the restoration of the Hotel; provided further, Operator may terminate this Agreement upon thirty days’ prior written notice to Owner if forty percent (40%) or more of the rooms in the Hotel are unavailable for rental for a period of one hundred eighty (180) days or more as a result of such casualty.
Insured Casualty In the case of damage by fire or other perils covered by the insurance carried or required to be carried pursuant to Article 11, provided that neither Landlord nor Tenant terminates this Lease as provided herein, Landlord shall as soon as possible commence such repair, reconstruction and restoration of the Premises and shall diligently prosecute the same to completion, but Landlord shall not be required to restore Tenant’s trade fixtures, equipment and personal property or Alterations made by Tenant after the Commencement Date (unless insurance proceeds are specifically designated for and available to restore such Alterations). Notwithstanding the foregoing, if (a) the Premises is destroyed to an extent of at least fifty percent (50%) of the then full replacement cost thereof as of the date of destruction, (b) the destruction occurs during the last year of the Term (as it may have been extended), or (c) the Premises is damaged by any peril and, because of the laws then in force, the Premises cannot be used for the same use being made thereof before such damage, then Tenant and Landlord shall each have the right to terminate this Lease. A party may exercise this termination right by giving written notice to the other party within thirty (30) days after the date of such destruction. In addition, Landlord shall have the option to terminate this Lease in the event the Premises is damaged by any peril to such an extent that the estimated cost to restore the Premises exceeds the insurance proceeds received by Landlord by more than $250,000, which option may be exercised only by delivery to Tenant of a written notice of election to terminate before the 45th day after Landlord’s receipt of the insurance proceeds. Notwithstanding the foregoing, Tenant may, at its election (but shall not be obligated to), provide Landlord with funds to cover such shortfall, within thirty (30) days after Tenant’s receipt of Landlord’s termination notice, in which event Landlord shall complete its repair, reconstruction and restoration of the Premises pursuant to this Article and this Lease shall remain in full force and effect. If this Lease is not terminated pursuant to the provisions of this Section 12.1, then the destruction will not terminate this Lease, and all obligations of Tenant under this Lease will remain in effect, except that, to the extent rental interruption insurance proceeds are paid to Landlord (or would have been paid, but for Landlord’s breach of Section 11.2(a)), the Monthly Rental and Operating Expenses will be abated or reduced, between the date of the destruction and the date of completion of restoration, by the ratio of (a) the area of the Premises rendered unusable or inaccessible by the destruction to (b) the area of the Premises before the destruction, or abated entirely if the remaining portion of the Premises is not sufficient for the conduct of Tenant’s business. The foregoing shall not affect Tenant’s rights set forth in Section 12.3 below.
Uninsured Casualty Subject to Section 7.2.2, any deductible amount payable under the property insurance for the Building(s) in which the Premises are located shall be an Operating Expense. In the event that the Premises or any portion of the Building(s) is damaged to the extent Tenant is unable to use the Premises and the event of damage or destruction is not fully covered by insurance that the Landlord is required to maintain pursuant to this Lease or in the event that the holder of any indebtedness secured by the Premises requires in accordance with California law, that the insurance proceeds be applied to such indebtedness, then Landlord shall have the right, at Landlord’s option, either to (i) repair such damage as soon as reasonably possible at Landlord’s expense or (ii) give written notice to Tenant within thirty (30) days after the date of the occurrence of such damage of Landlord’s intention to terminate this Lease as of the date of the occurrence of such damage. In the event Landlord elects to terminate this Lease, Tenant shall have the right within thirty (30) days after receipt of such notice to give written notice to Landlord of Tenant’s intention to pay the cost of repair of such damage, in which event, following the securitization of Tenant’s funding commitment in a form reasonably acceptable to Landlord, this Lease shall continue in full force and effect. Landlord shall make such repairs as soon as reasonably possible, and Tenant shall reimburse Landlord for such repairs within thirty (30) days after receipt of an invoice from Landlord. If Tenant does not give such notice within the thirty (30) day period, this Lease shall terminate automatically as of the Casualty Date.
Damage; Strike; Casualty Any material damage to, or loss, theft or destruction of, any Property, whether or not insured, or any strike, lockout, labor dispute, embargo, condemnation, act of God or public enemy, or other casualty which causes, for more than 30 consecutive days beyond the coverage period of any applicable business interruption insurance, the cessation or substantial curtailment of revenue producing activities of the Borrower and its Subsidiaries, taken as a whole, and only if any such event or circumstance could reasonably be expected to have a Material Adverse Effect.
Damage or Destruction If all or a portion of the Subleased Premises is destroyed or damaged as described in Article 10 of the Master Lease: (i) Sublandlord shall have no obligation or liability to Subtenant in connection with any such damage or destruction, (ii) this Sublease shall continue only to the extent the Master Lease remains in effect pursuant to Article 10 of the Master Lease (and Sublandlord shall provide Subtenant with any notices by Master Landlord in connection therewith), (iii) Subtenant shall be entitled to an abatement of Rent to the extent that the Subleased Premises shall have been rendered Untenantable until substantially repaired, but only to the extent that Sublandlord’s rent under the Master Lease has been abated (on the same percentage basis that Sublandlord’s rent is abated), and (iv) Subtenant shall have the same rights to terminate this Sublease as Sublandlord has to terminate the Master Lease, as provided in the Master Lease. Sublandlord shall use commercially reasonable efforts to enforce Sublandlord’s rights under Article 10 of the Master Lease. If the destruction or damage relates solely to the Subleased Premises, then Subtenant shall have the right to approve any settlement of Sublandlord’s rights under the Master Lease relating to such casualty, which approval shall not be unreasonably withheld or delayed. In all other cases, Subtenant shall be entitled to participate with Sublandlord in the enforcement of Sublandlord’s rights under Article 10 of the Master Lease, provided that the final settlement in any such case shall be made by Sublandlord.
Insurance Casualty Condemnation Restoration SECTION 8.1. INSURANCE SECTION 8.2. CASUALTY SECTION 8.3. CONDEMNATION SECTION 8.4. RESTORATION
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Insurance Casualty Condemnation Seller agrees that it will keep the Property insured against casualty until the Closing Date under its existing insurance policies or replacement policies with the same coverage as existing at the date of execution hereof. Such policies shall be terminated by Seller at the Closing Date. In the event that, prior to the Closing Date, all or any portion of the Property shall be destroyed by fire or other casualty, or taken by condemnation or exercise of the right of eminent domain, or if proceedings therefor shall be instituted or threatened and the amount of any such damage or condemnation exceeds $100,000, then Buyer may, within ten (10) days of its receipt of notice of such event, elect to terminate this Agreement by written notice to Seller and Escrow Agent. If the damage or condemnation is equal to or less than $100,000 or if the damage or condemnation exceeds $100,000 but Buyer does not terminate this Agreement, then the parties shall proceed to close the transaction contemplated hereby, in which event any insurance or condemnation proceeds (excluding rental loss proceeds attributable to the period prior to the Closing Date) shall inure to the benefit of Buyer and shall be assigned by Seller to Buyer at close of Escrow. In the event the parties proceed to close the transaction contemplated hereby, Seller shall pay any required deductible applicable to such insurance coverage, or the Purchase Price shall be reduced by the amount of any such deductible.
