Tenant Delays and Increased Costs
Tenant Delays and Increased Costs Sample Clauses
Related to Tenant Delays and Increased Costs
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Changes in Laws and Increased Costs of Loans (a) Notwithstanding anything to the contrary contained herein, all Eurodollar Rate Loans shall, upon notice by Lender to Borrower, convert to Prime Rate Loans in the event that (i) any change in applicable law or regulation (or the interpretation or administration thereof) shall either (A) make it unlawful for Lender, Reference Bank or any participant to make or maintain Eurodollar Rate Loans or to comply with the terms hereof in connection with the Eurodollar Rate Loans, or (B) shall result in the increase in the costs to Lender, Reference Bank or any participant of making or maintaining any Eurodollar Rate Loans by an amount deemed by Lender to be material, or (C) reduce the amounts received or receivable by Lender in respect thereof, by an amount deemed by Lender to be material or (ii) the cost to Lender, Reference Bank or any participant of making or maintaining any Eurodollar Rate Loans shall otherwise increase by an amount deemed by Lender to be material. Borrower shall pay to Lender, upon demand by Lender (or Lender may, at its option, charge any loan account of Borrower) any amounts required to compensate Lender, the Reference Bank or any participant with Lender for any loss (including loss of anticipated profits), cost or expense incurred by such person as a result of the foregoing, including, without limitation, any such loss, cost or expense incurred by reason of the liquidation or reemployment of deposits or other funds acquired by such person to make or maintain the Eurodollar Rate Loans or any portion thereof. A certificate of Lender setting forth the basis for the determination of such amount necessary to compensate Lender as aforesaid shall be delivered to Borrower and shall be conclusive, absent manifest error. (b) If any payments or prepayments in respect of the Eurodollar Rate Loans are received by Lender other than on the last day of the applicable Interest Period (whether pursuant to acceleration, upon maturity or otherwise), including any payments pursuant to the application of collections under Section 6.3 or any other payments made with the proceeds of Collateral, Borrower shall pay to Lender upon demand by Lender (or Lender may, at its option, charge any loan account of Borrower) any amounts required to compensate Lender, the Reference Bank or any participant with Lender for any additional loss (including loss of anticipated profits), cost or expense incurred by such person as a result of such prepayment or payment, including, without limitation, any loss, cost or expense incurred by reason of the liquidation or reemployment of deposits or other funds acquired by such person to make or maintain such Eurodollar Rate Loans or any portion thereof.
Increased Costs (a) If any Change in Law shall: (i) impose, modify or deem applicable any reserve, special deposit or similar requirement against assets of, deposits with or for the account of, or credit extended by, any Lender (except any such reserve requirement reflected in the Adjusted LIBO Rate); or (ii) impose on any Lender or the London interbank market any other condition (other than one relating to Excluded Taxes) affecting this Agreement or Eurodollar Loans made by such Lender; and the result of any of the foregoing shall be to increase the cost to such Lender of making or maintaining any Eurodollar Loan (or of maintaining its obligation to make any such Loan) or to reduce the amount of any sum received or receivable by such Lender hereunder (whether of principal, interest or otherwise), then the Borrower will pay to such Lender such additional amount or amounts as will compensate such Lender for such additional costs incurred or reduction suffered. (b) If any Lender determines that any Change in Law regarding capital requirements has or would have the effect of reducing the rate of return on such Lender’s capital or on the capital of such Lender’s holding company, if any, as a consequence of this Agreement or the Loans made by such Lender, to a level below that which such Lender or such Lender’s holding company could have achieved but for such Change in Law (taking into consideration such Lender’s policies and the policies of such Lender’s holding company with respect to capital adequacy), then from time to time the Borrower will pay to such Lender, as the case may be, such additional amount or amounts as will compensate such Lender or such Lender’s holding company for any such reduction suffered. (c) A certificate of a Lender setting forth the amount or amounts necessary to compensate such Lender or its holding company, as the case may be, as specified in paragraph (a) or (b) of this Section shall be delivered to the Borrower and shall be conclusive absent manifest error. The Borrower shall pay such Lender, the amount shown as due on any such certificate within 10 days after receipt thereof. (d) Failure or delay on the part of any Lender to demand compensation pursuant to this Section shall not constitute a waiver of such Lender’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender pursuant to this Section for any increased costs or reductions incurred more than 270 days prior to the date that such Lender notifies the Lead Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 270-day period referred to above shall be extended to include the period of retroactive effect thereof.
Increased Costs, Etc (a) If, due to either (i) the introduction of or any change in or in the interpretation of any law or regulation or (ii) the compliance with any guideline or request from any central bank or other Governmental Authority (whether or not having the force of law), there shall be any increase in the cost to any Lender Party of agreeing to make or of making, funding or maintaining Eurodollar Rate Advances (excluding, for purposes of this Section 2.10, any such increased costs resulting from (y), Taxes described in clauses (ii) and (iii) of the definition of Excluded Taxes, Indemnified Taxes or Other Taxes (as to which Section 2.12 shall govern) and (z) changes in the basis of taxation of overall net income or overall gross income by the United States or by the foreign jurisdiction or state under the laws of which such Lender Party is organized, has its Applicable Lending Office or otherwise has current or former connections (other than such connections arising from such Lender Party’s having executed, delivered, became a party to, performed its obligations under, received or perfected a security interest under, engaged in any other transactions pursuant to, or enforced any Loan Documents, or sold or assigned any interest in any Obligations or Loan Document) or any political subdivision thereof), then the Borrower shall from time to time, upon demand by such Lender Party (with a copy of such demand to the Administrative Agent), pay to the Administrative Agent for the account of such Lender Party additional amounts sufficient to compensate such Lender Party for such increased cost; provided, however, that a Lender Party claiming additional amounts under this Section 2.10(a) agrees to use reasonable efforts (consistent with its internal policy and legal and regulatory restrictions) to designate a different Applicable Lending Office if the making of such a designation would avoid the need for, or reduce the amount of, such increased cost that may thereafter accrue and would not, in the reasonable judgment of such Lender Party, be otherwise disadvantageous to such Lender Party. A certificate as to the amount of such increased cost, submitted to the Borrower by such Lender Party, shall be conclusive and binding for all purposes, absent manifest error. Notwithstanding anything to the contrary contained in this Agreement, the Xxxx-Xxxxx Xxxx Street Reform and Consumer Protection Act, as amended, and all requests, rules, guidelines or directives thereunder or issued in connection therewith, regardless of the date enacted, adopted or issued shall be deemed an introduction or change of the type referred to in subclause (i) of this Section 2.10(a). (b) If any Lender Party determines that compliance with any law or regulation or any guideline or request from any central bank or other Governmental Authority (whether or not having the force of law) affects or would affect the amount of capital or liquidity required or expected to be maintained by such Lender Party or any corporation controlling such Lender Party and that the amount of such capital or such liquidity requirement is increased by or based upon the existence of such Lender Party’s commitment to lend hereunder and other commitments of such type (or similar contingent obligations), then, upon demand by such Lender Party or such corporation (with a copy of such demand to the Administrative Agent), the Borrower shall pay to the Administrative Agent for the account of such Lender Party, from time to time as specified by such Lender Party, additional amounts sufficient to compensate such Lender Party in the light of such circumstances, to the extent that such Lender Party reasonably determines such increase in capital or increase in liquidity to be allocable to the existence of such Lender Party’s commitment to lend hereunder. A certificate as to such amounts submitted to the Borrower by such Lender Party shall be conclusive and binding for all purposes, absent manifest error. Notwithstanding anything to the contrary contained in this Agreement, the Xxxx-Xxxxx Xxxx Street Reform and Consumer Protection Act, as amended, and all requests, rules, guidelines or directives thereunder or issued in connection therewith, regardless of the date enacted, adopted or issued, and all requests, rules, guidelines or directives promulgated by the Bank for International Settlements or the Basel Committee on Banking Supervision (or any successor or similar authority) shall be deemed an introduction or change of the type referred to in Section 2.10(a) and this Section 2.10(b). (c) If, with respect to any Eurodollar Rate Advances, the Required Lenders notify the Administrative Agent that the Eurodollar Rate for any Interest Period for such Advances will not adequately reflect the cost to such Lenders of making, funding or maintaining their Eurodollar Rate Advances for such Interest Period, the Administrative Agent shall forthwith so notify the Borrower and the Lenders, whereupon (i) each such Eurodollar Rate Advance will automatically, on the last day of the then existing Interest Period therefor, Convert into a Base Rate Advance and (ii) the obligation of the Lenders to make, or to Convert Advances into, Eurodollar Rate Advances shall be suspended until the Administrative Agent shall notify the Borrower that such Lenders have determined that the circumstances causing such suspension no longer exist. (d) Notwithstanding any other provision of this Agreement, if the introduction of or any change in or in the interpretation of any law or regulation shall make it unlawful, or any central bank or other Governmental Authority shall assert that it is unlawful, for any Lender or its Eurodollar Lending Office to perform its obligations hereunder to make Eurodollar Rate Advances or to continue to fund or maintain Eurodollar Rate Advances hereunder, then, on notice thereof and demand therefor by such Lender to the Borrower through the Administrative Agent, (i) each Eurodollar Rate Advance will automatically, upon such demand, Convert into a Base Rate Advance and (ii) the obligation of the Lenders to make, or to Convert Advances into, Eurodollar Rate Advances shall be suspended until the Administrative Agent shall notify the Borrower that such Lender has determined that the circumstances causing such suspension no longer exist; provided, however, that, before making any such demand, such Lender agrees to use reasonable efforts (consistent with its internal policy and legal and regulatory restrictions) to designate a different Eurodollar Lending Office if the making of such a designation would allow such Lender or its Eurodollar Lending Office to continue to perform its obligations to make Eurodollar Rate Advances or to continue to fund or maintain Eurodollar Rate Advances and would not, in the judgment of such Lender, be otherwise disadvantageous to such Lender.
Increased Costs Generally If any Change in Law shall: (i) impose, modify or deem applicable any reserve, special deposit, compulsory loan, insurance charge or similar requirement against assets of, deposits with or for the account of, or credit extended or participated in by, any Lender (except any reserve requirement contemplated by Section 3.04(e)) or the L/C Issuer; (ii) subject any Lender or the L/C Issuer to any tax of any kind whatsoever with respect to this Agreement, any Letter of Credit, any participation in a Letter of Credit or any Eurodollar Rate Loan made by it, or change the basis of taxation of payments to such Lender or the L/C Issuer in respect thereof (except for Indemnified Taxes or Other Taxes covered by Section 3.01 and the imposition of, or any change in the rate of, any Excluded Tax payable by such Lender or the L/C Issuer); or (iii) impose on any Lender or the L/C Issuer or the London interbank market any other condition, cost or expense affecting this Agreement or Eurodollar Rate Loans made by such Lender or any Letter of Credit or participation therein; and the result of any of the foregoing shall be to increase the cost to such Lender of making or maintaining any Eurodollar Rate Loan (or of maintaining its obligation to make any such Loan), or to increase the cost to such Lender or the L/C Issuer of participating in, issuing or maintaining any Letter of Credit (or of maintaining its obligation to participate in or to issue any Letter of Credit), or to reduce the amount of any sum received or receivable by such Lender or the L/C Issuer hereunder (whether of principal, interest or any other amount) then, upon request of such Lender or the L/C Issuer, the Borrower will pay to such Lender or the L/C Issuer, as the case may be, such additional amount or amounts as will compensate such Lender or the L/C Issuer, as the case may be, for such additional costs incurred or reduction suffered.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Increased Costs Reserves on Eurodollar Rate Loans (a) If any Change in Law shall: (i) impose, modify or deem applicable any reserve, special deposit, compulsory loan, insurance charge or similar requirement against assets of, deposits with or for the account of, or credit extended or participated in by, any Lender (except any reserve requirement reflected in the Eurodollar Rate) or the L/C Issuer; (ii) subject any Lender or any L/C Issuer to any tax of any kind whatsoever with respect to this Agreement, any Letter of Credit, any participation in a Letter of Credit or any Eurodollar Rate Loan made by it, or change the basis of taxation of payments to such Lender or any L/C Issuer in respect thereof 068800 000057 DALLAS 1872243.4 (except for Indemnified Taxes or Other Taxes covered by Section 3.01 and the imposition of, or any change in the rate of, any Excluded Tax payable by such Lender or any L/C Issuer); or (iii) impose on any Lender or any L/C Issuer or the London interbank market any other condition, cost or expense affecting this Agreement or Eurodollar Rate Loans made by such Lender or any Letter of Credit or participation therein; and the result of any of the fgoing shall be to increase the cost to such Lender of making or maintaining any Eurodollar Rate Loan (or of maintaining its obligation to make any such Loan), or to increase the cost to such Lender or such L/C Issuer of participating in, issuing or maintaining any Letter of Credit (or of maintaining its obligation to participate in or to issue any Letter of Credit), or to reduce the amount of any sum received or receivable by such Lender or such L/C Issuer hereunder (whether of principal, interest or any other amount) then, upon request of such Lender or such L/C Issuer, the Borrower will pay to such Lender or such L/C Issuer, as the case may be, such additional amount or amounts as will compensate such Lender or such L/C Issuer, as the case may be, for such additional costs incurred or reduction suffered. (b) If any Lender or any L/C Issuer determines that any Change in Law affecting such Lender or such L/C Issuer or any Lending Office of such Lender or such Lender’s or such L/C Issuer’s holding company, if any, regarding capital requirements has or would have the effect of reducing the rate of return on such Lender’s or such L/C Issuer’s capital or on the capital of such Lender’s or such L/C Issuer’s holding company, if any, as a consequence of this Agreement, the Commitments of such Lender or the Loans made by, or participations in Letters of Credit held by, such Lender, or the Letters of Credit issued by such L/C Issuer, to a level below that which such Lender or such L/C Issuer or such Lender’s or such L/C Issuer’s holding company could have achieved but for such Change in Law (taking into consideration such Lender’s or such L/C Issuer’s policies and the policies of such Lender’s or such L/C Issuer’s holding company with respect to capital adequacy), then from time to time the Borrower will pay to such Lender or such L/C Issuer, as the case may be, such additional amount or amounts as will compensate such Lender or such L/C Issuer or such Lender’s or such L/C Issuer’s holding company for any such reduction suffered. (c) A certificate of a Lender or a L/C Issuer setting forth the amount or amounts necessary to compensate such Lender or such L/C Issuer or its holding company, as the case may be, as specified in subsection (a) or (b) of this Section and delivered to the Borrower shall be conclusive absent manifest error. The Borrower shall pay such Lender or such L/C Issuer, as the case may be, the amount shown as due on any such certificate within 10 days after receipt thereof. (d) Failure or delay on the part of any Lender or any L/C Issuer to demand compensation pursuant to the foregoing provisions of this Section shall not constitute a waiver of such Lender’s or such L/C Issuer’s right to demand such compensation, provided that the Borrower shall not be required to compensate a Lender or a L/C Issuer pursuant to the foregoing provisions of this Section for any increased costs incurred or 068800 000057 DALLAS 1872243.4 reductions suffered more than nine months prior to the date that such Lender or such L/C Issuer, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or such L/C Issuer’s intention to claim compensation therefor (except that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the nine-month period referred to above shall be extended to include the period of retroactive effect thereof).
Increased cost claims (a) A Finance Party intending to make a claim pursuant to Clause 13.1 (Increased costs) shall notify the Agent of the event giving rise to the claim, following which the Agent shall promptly notify the Borrower. (b) Each Finance Party shall, as soon as practicable after a demand by the Agent, provide a certificate confirming the amount of its Increased Costs.
