Tenant Inducement Costs, Leasing Commissions and Construction Contracts Sample Clauses

Tenant Inducement Costs, Leasing Commissions and Construction Contracts. 4.3.7.1 Purchaser shall be responsible for the payment of all of the following Tenant Inducement Costs (as defined below): (a) those specifically identified as Purchaser’s obligation on Exhibit K-1 of the Company Disclosure Letter; and (b) those set forth in a Lease existing as of the Effective Date which, pursuant to such Lease, do not relate to the current term of such Lease. In addition, Purchaser shall reimburse Sellers for the amount that Sellers pay for any third-party legal services provided in connection with the negotiation and entering into of any new Lease, subject to the amounts set forth on Exhibit K-1 to the Company Disclosure Letter. Sellers shall be responsible for the payment of those Tenant Inducement Costs specifically identified as Sellers’ obligations on Exhibit K-1 to the Company Disclosure Letter (the aggregate amount of which is estimated to be $17,433,849.68 as of February 12, 2018 and subject to change based on the actual Closing Date).
Sample 1
AutoNDA by SimpleDocs
Tenant Inducement Costs, Leasing Commissions and Construction Contracts. 4.3.7.1 Purchaser shall be responsible for the payment of all of the following Tenant Inducement Costs (as defined below): (a) those specifically identified as Purchaser’s obligation on Exhibit K-1 of the Company Disclosure Letter; (b) those payable under a New Lease entered into in accordance with Section 9.3.1 below (in an amount equal to the amount of such costs prorated over the term of such New Lease, with Seller being responsible only for the portion of such costs based on the ratio of base rent payments received by Nine Penn Owner through the Closing Date to the total base rent payable over the term of such New Lease); and (c) those associated with existing Leases other than with respect to the current terms of such existing Leases. Seller shall be responsible for the payment of all Tenant Inducement Costs with respect to the current term of all existing Leases and other than those for which Purchaser is expressly responsible pursuant to Section 4.3.7.1 above.
Sample 1
Tenant Inducement Costs, Leasing Commissions and Construction Contracts. Except as may be set forth in the Company Disclosure Letter: 4.3.7.1 Purchaser shall be responsible for the payment of all of the following Tenant Inducement Costs (as defined below): (a) those specifically identified as Purchaser’s obligation on Exhibit K-1 to the Company Disclosure Letter; (b) those payable under a New Lease and not designated as Seller’s responsibility in clause (ii) of the next paragraph; and (c) those set forth in a Lease existing as of the date hereof, which, pursuant to the such Lease, are not due and payable prior to the Closing Date. In addition, Purchaser shall reimburse Seller for the amount that Seller pays for any third-party legal services provided in connection with the negotiation and entering into of any New Lease approved or deemed approved by Purchaser in accordance with Section 9.3.1 below and in effect as of the Closing Date. At the Closing Purchaser shall be entitled to a credit against the Purchase Price in the amount shown on Exhibit K-1 to the Company Disclosure Letter with respect to certain free rent set forth thereon for the period from and after Closing (“Free Rent Credit”). Seller shall be responsible for the payment of all of the following Tenant Inducement Costs: (i) those specifically identified as Seller’s obligations on Exhibit K-1 to the Company Disclosure Letter; and (ii) those paid or payable in connection with any New Lease entered into in accordance with Section 9.3.1 below (in an amount equal to the amount of such costs prorated over the term of such New Lease, with Seller being responsible only for the portion of such costs based on the ratio of base rent payments received by Seller through the Closing Date to the total base rent payable over the term of such New Lease).
Sample 1
Tenant Inducement Costs, Leasing Commissions and Construction Contracts 
Sample 1

Related to Tenant Inducement Costs, Leasing Commissions and Construction Contracts

  • Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.

  • Leasing Commissions On or before the Closing Date, Seller shall pay in full all leasing commissions due to leasing or other agents for the current remaining term of the Lease (determined without regard to any unexercised termination or cancellation right).

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Leasing Costs The Sellers shall be responsible for all Leasing Costs that are payable by reason of (i) the execution of an “Existing Lease” (i.e., a Lease existing as of the date of this Agreement) prior to the date of this Agreement, (ii) the renewal, extension, expansion of, or the exercise of any other option under, an Existing Lease, prior to the date of this Agreement, and (iii) amendments of an Existing Lease entered into prior to the date of this Agreement. If the Closing occurs, the Buyer shall be responsible for all Leasing Costs (including commissions to the Sellers’ in-house leasing agents that are customary arms-length terms that would otherwise be negotiated with a third-party leasing agent) that become due and payable as a result of (1) any New Leases, (2) amendments entered into during the Interim Period in accordance with this Agreement to renew, extend, expand or otherwise amend Existing Leases or New Leases, or (3) any renewals, extensions or expansions of, or the exercise of any other option under, Existing Leases or New Leases exercised by tenants during the Interim Period or on or after the Closing Date; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. In addition, the Buyer shall assume the economic effect of any “free rent” or other concessions pertaining to the period from and after the Closing; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. If, as of the Closing Date, the Sellers shall have paid any Leasing Costs for which the Buyer is responsible pursuant to the foregoing provisions, the Buyer shall reimburse the Sellers therefor at Closing; provided, however, that Buyer shall have been provided the details of all such Leasing Costs prior to the Closing Date and approved the same in writing. The Sellers shall pay (or cause to be paid), prior to Closing, or credit the Buyer at Closing (to the extent unpaid) all Leasing Costs for which the Sellers are responsible pursuant to the foregoing provisions, and (subject to the reimbursement obligations set forth above), the Sellers shall pay (or cause to be paid) when due all Leasing Costs payable after the date of this Agreement and prior to Closing. Notwithstanding anything to the contrary, (a) the Buyer shall receive a credit at Closing for any unfunded contractual Leasing Costs and (b) the Sellers shall be responsible (and the Buyer shall not be responsible) for any leasing commissions or brokerage fees which become due and payable after the Closing pursuant to any leasing or brokerage agreement relating to the Properties, including the Leasing and Brokerage Agreements, except as specifically set forth in Section 3.3(g)(ii). In addition to the foregoing, at Closing, the Buyer shall be responsible (and shall reimburse the Sellers at Closing) for the leasing commissions, tenant improvement costs and concessions for the Leases and the amounts set forth on Schedule 3.3(g)(ii) attached hereto. For purposes hereof, the term “Interim Period” shall mean the period from the date of this Agreement until the Closing Date. On the Closing Date, the Sellers shall deliver to the Buyer all Lease Termination Payments received by or on behalf of the Sellers from and after the date hereof, except, however, the Buyer acknowledges approval of the Leases referenced on Schedule 3.3(g)(ii).

  • Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Space Leases (i) To Borrower’s best knowledge, Borrower has delivered a true, correct and complete schedule of all Space Leases as of the date hereof, which accurately and completely sets forth in all material respects, for each such Space Lease, the following (collectively, the “Rent Roll”): the name and address of the tenant; the lease expiration date, extension and renewal provisions; the base rent and percentage rent payable; and the security deposit held thereunder. (ii) Each Space Lease constitutes the legal, valid and binding obligation of Borrower or, the Operating Tenant, as applicable, and, to the knowledge of Borrower, is enforceable against the tenant thereof. No default exists, or with the passing of time or the giving of notice would exist, which would, in the aggregate, have a Material Adverse Effect. (iii) To Borrower’s best knowledge, no tenant under any Major Space Lease has, as of the date hereof, paid Rent more than thirty (30) days in advance, and the Rents under such Major Space Leases have not been waived, released, or otherwise discharged or compromised. (iv) To Borrower’s best knowledge, except as disclosed in writing to Lender, all work to be performed by Borrower under the Space Leases has been substantially performed, all contributions to be made by Borrower to the tenants thereunder have been made except for any held-back amounts, and all other conditions precedent to each such tenant’s obligations thereunder have been satisfied. (v) To Borrower’s best knowledge, except as previously disclosed to Lender in writing or contained in the Space Leases, there are no options to terminate any Space Lease. (vi) To Borrower’s best knowledge, each tenant under a Major Space Lease or such tenant’s authorized subtenant is currently occupying the space demised by such Major Space Lease. (vii) To Borrower’s best knowledge, Borrower has delivered to Lender true, correct and complete copies of all Space Leases described in the Rent Roll. (viii) No Space Lease has been assigned or, to Borrower’s best knowledge, modified, supplemented or amended in any way. (ix) To Borrower’s best knowledge, each tenant under each Space Lease is free from bankruptcy, reorganization or arrangement proceedings or a general assignment for the benefit of creditors. (x) To Borrower’s best knowledge, no Space Lease provides any party with the right to obtain a lien or encumbrance upon the Property superior to the lien of this Security Instrument.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Existing Leases During the period from the expiration of the Inspection Period through Closing (or earlier termination of this Agreement or default by Buyer hereunder), Seller shall not enter into new leases for portions of the Premises now vacant or for portions of the Premises which may become vacant, or enter into any amendments of any Existing Leases or consent to any renewals, extensions or expansions of Existing Leases or agree to any rental concessions (other than (i) those to which the tenant is entitled pursuant to the terms of the Existing Leases, (ii) those for which the rent is greater than the rent shown on the Rent Roll (as hereinafter defined) for the applicable unit, (iii) the following rental concessions: 10% discounts for law enforcement officers, 5% discount for teachers, 5% discount for hospital personnel, and 3% discount for senior citizens (such discounts are taken off market rent, on one year leases only and cannot be combined with any other discount or concession), so long as not more than twenty (20) new leases subject to such concessions are executed after the expiration of the Inspection Period, and (iv) those rental concessions which are paid by Seller prior to the Closing Date, and in all events using forms substantially the same as those used for the Existing Leases) without first submitting such a copy of such proposed lease or lease amendment (including any renewal, extension or expansion as to which the lessor's consent is required) to Buyer for Buyer's approval. If Buyer does not disapprove in writing such a proposed lease or amendment (or renewal, extension or expansion agreement) within five (5) business days of Buyer's receipt of a copy thereof, Buyer shall be deemed to have approved the proposed lease or amendment (or renewal, extension or expansion agreement). All such new leases and modifications approved or deemed approved by Buyer (and renewals, extensions or expansions approved or deemed approved by Buyer or as to which the lessor's consent is not required), all new leases entered into prior to the expiration of the Inspection Period, and the presently existing leases that are listed on Exhibit "C" hereto are collectively herein called the "Existing Leases". The termination or expiration of any of the Existing Leases prior to Closing shall not excuse Buyer from its obligation to complete Closing and to pay the full Purchase Price.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!