Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.
Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Construction Phase During Construction, DESIGN/BUILDER shall provide Engineering and Design Professional Services as necessary to complete the Project.
Tenant’s Repairs and Maintenance Tenant covenants and agrees that, from and after the date that possession of the Premises is delivered to Tenant and until the end of the Lease Term, Tenant will keep neat and clean and maintain in good order, condition and repair the Premises and every part thereof, excepting only for those repairs for which Landlord is responsible under the terms of Article VII of this Lease and damage by fire or casualty and as a consequence of the exercise of the power of eminent domain. Tenant shall not permit or commit any waste, and Tenant shall be responsible for the cost of repairs which may be made necessary by reason of damages to common areas in the Building or Prudential Center by Tenant, Tenant’s agents, employees, contractors, sublessees, licensees, concessionaires or invitees. Tenant shall maintain all its equipment, furniture and furnishings in good order and repair. If repairs are required to be made by Tenant pursuant to the terms hereof, Landlord may demand that Tenant make the same forthwith, and if Tenant refuses or neglects to commence such repairs and complete the same with reasonable dispatch after such demand, Landlord may (but shall not be required to do so) make or cause such repairs to be made and shall not be responsible to Tenant for any loss or damage that may accrue to Tenant’s stock or business by reason thereof. If Landlord makes or causes such repairs to be made, Tenant agrees that Tenant will forthwith on demand, pay to Landlord as Additional Rent the cost thereof together with interest thereon at the rate specified in Section 16.21, and if Tenant shall default in such payment, Landlord shall have the remedies provided for non-payment of rent or other charges payable hereunder.
Maintenance and Repairs by Tenant Tenant, at its expense, shall --------------------------------- maintain and repair the interior of the Leased Premises, and all heating, air conditioning, ventilating, electrical, mechanical, sprinkler and plumbing systems, equipment, machinery or fixtures exclusively servicing the Leased Premises, together with all pipes, conduits, ducts and drains therefor. Furthermore Tenant, at its expense, shall replace any broken glass in the interior or exterior of the Leased Premises, and shall maintain and repair all entryway doors to the Leased Premises. Landlord shall assign to Tenant all assignable manufacturers' warranties with respect to equipment and fixtures installed in the Leased Premises. Tenant further agrees to keep the Leased Premises in good, tenantable, sanitary, sightly and clean condition and to keep all lobbies and entryways which are part of the Leased Premises clean and free from debris, refuse, obstructions or hazardous conditions. Tenant agrees to notify Landlord in the event an excessive amount of snow accumulates on the roof of the Leased Premises. Tenant shall be responsible for all maintenance or repairs wholly or partially (to the extent of Tenant's part) caused by the negligence or fault of Tenant or any of its agents, visitors or licensees, or by Tenant's breach of any provision of this Agreement. If Tenant does not make the repairs or perform the maintenance required hereunder in a prompt and adequate manner, then after notice to Tenant and opportunity cure as provided herein, Landlord may make such repairs or perform such maintenance and pay the costs thereof, and such costs shall be so much Additional Rent which shall become immediately due and payable by Tenant to Landlord.
