Occupancy After Foreclosure Any sale of the Mortgaged Property or any part thereof will divest all right, title and interest of Mortgagor in and to the property sold. Subject to applicable law, any purchaser at a foreclosure sale will receive immediate possession of the property purchased. If Mortgagor retains possession of such property or any part thereof subsequent to such sale, Mortgagor will be considered a tenant at sufferance of the purchaser, and will, if Mortgagor remains in possession after demand to remove, be subject to eviction and removal, forcible or otherwise, with or without process of law.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Tenant Repairs To repair, maintain and keep the Leased Premises and all trade fixtures and improvements therein in good and substantial repair subject only to defects in construction of the structural members of the Building, reasonable wear and tear and damage by fire, lightning and tempest or other casualty against which the Landlord is insured (herein collectively referred to as "Tenant Repair Exceptions"); and that the Landlord may enter and view state of repair and that the Tenant will repair according to notice in writing, except for Tenant Repair Exceptions and that the Tenant will leave the Leased Premises in good repair, except for Tenant Repair Exceptions. Notwithstanding anything hereinbefore contained, the Landlord may in any event make repairs to the Leased Premises without notice if such repairs are, in the Landlord's opinion, necessary for the protection of the Building and the Tenant covenants and agrees with the Landlord that if the Landlord exercises any such option to repair, the Tenant will pay to the Landlord together with the next instalment of Monthly Rent which shall become due after the exercise of such option all sums which the Landlord shall have expended in making such repairs and that such sums, if not so paid within such time, shall be recoverable from the Tenant as rent in arrears. Provided further that in the event that the Landlord from time to time makes any repairs as hereinbefore provided, the Tenant shall not be deemed to have been relieved from the obligation to repair and leave the Leased Premises in a good state of repair.
Construction of Tenant Improvements Tenant shall install the Tenant Improvements (as described in Paragraph 2(a) below) in accordance with the terms and conditions of this Work Letter. The quantities, character and manner of installation of all of the work related to the Tenant Improvements shall be subject to the limitations imposed by any applicable governmental regulations, laws, ordinances, codes and rules. Notwithstanding the foregoing, Landlord may at Landlord’s sole election itself (with Landlord’s contractor) construct the portion of the Tenant Improvements that consist of the restrooms and related improvements that will service Building 2 (the “Restroom Improvements”), at Tenant’s cost up to a maximum amount of $322,764 (subject to Section 9(b) below), provided that (a) Landlord notifies Tenant in writing of such election prior to Tenant’s commencement of construction of the Tenant Improvements, and (b) Landlord shall use commercially reasonable efforts to not unreasonably interfere with or delay Tenant’s installation of the Tenant Improvements. If a certificate of occupancy or equivalent permit sign-off for the Premises is delayed beyond the Building 2 Scheduled Commencement Date solely as a result of Landlord’s failure to substantially complete the Restroom Improvements prior to such date, which failure does not result from Tenant Delays (as defined below) or Force Majeure, then the Building 2 Commencement Date shall be extended day for day by the number of days after the Building 2 Scheduled Commencement Date until the issuance of a certificate of occupancy or equivalent permit sign-off (but in no event shall the Building 2 Commencement Date be delayed beyond the date Tenant commences business in the Premises), provided, however, that Tenant delivers written notice to Landlord at such time as Tenant becomes aware that Landlord is in danger of causing such delay. “Tenant Delays” shall mean (i) Tenant’s delay in submittal of Tenant’s Plans and/or responses to Landlord’s comments to Tenant’s Plans beyond the time periods provided in this Work Letter, (ii) Tenant’s delay in any submittals for permits or other governmental approvals with respect to the Tenant Improvements (including without limitation the Restroom Improvements), (iii) changes in Tenant’s Plans as they relate to the Restroom Improvements after they have been submitted to governmental authorities for permits, (iv) delay in obtaining materials for reasons outside Landlord’s reasonable control, and (v) Tenant’s failure to provide reasonable access to the Premises to Landlord’s contractors to install the Restroom Improvements, or unreasonable interference with such installation by Tenant or its contractors or agents.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter:
a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications).
b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows:
(i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and
(ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises.
c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Current Status Sacramento County recently adopted a revised American River Parkway Plan which includes specific policies related to implementing water flows protective of the lower American River ecosystem. The Parkway Plan serves as a guide for other local, state and federal agencies with authority within the American River Parkway under the Wild and Scenic Rivers Act and the Urban American River Parkway Preservation Act. Sacramento County, through the Water Forum, is in the process of preparing a draft environmental impact report to institute the FMS consistent with the American River Parkway Plan and the coequal goals of the Water Forum Agreement by entering into an operations agreement with Reclamation or by seeking to modify Reclamation’s Folsom Dam water right permits or other measures. Reclamation has been operating the Folsom and Nimbus Dams in accordance with the minimum release requirements of the FMS since 2006. In 2009, the National Marine Fisheries Service (NMFS) included the FMS flow, operational criteria, American River Group, and monitoring requirements in the Reasonable and Prudent Alternatives of the Biological Opinion (BO) for operating the CVP. The NMFS BO also called for an iterative temperature management planning process that is consistent with the water temperature objectives of the FMS. The Water Forum is currently investigating the potential for an improved Flow Standard for the lower American River that would provide increased protection of salmonid species and improved water supply reliability.
Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans.
(a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant.
(b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent.
(a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business.
(b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans.
(a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease.
(b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding.
3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant.
3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.
Tenant’s Repairs Tenant, at its expense, shall promptly make all repairs and replacements of every kind and nature, whether foreseen or unforeseen, which may be required to be made upon or in connection with the Premises. Landlord shall not be required to make any repair, whether foreseen or unforeseen, or to maintain any of the Premises in any way. Any repair or replacement shall be performed at the Tenant's expense by contractors approved by Landlord, or at Landlord's option, by Landlord. Such repair and replacements include capital expenditures and repairs whose benefit extend beyond the Lease Term. Heating, ventilation and air conditioning systems and other mechanical and building systems serving the Premises shall be maintained at Tenant's expense pursuant to maintenance service contracts entered into by Tenant. The scope of services and contractors under such maintenance contracts shall be reasonably approved by Landlord. If Tenant fails to perform any repair or replacement for which it is responsible, Landlord may perform such work and be reimbursed by Tenant within ten (10) days after demand therefor. Subject to the Restoration and Condemnation Paragraphs, Tenant shall bear the full cost of any repair or replacement to any part of the Premises that results from damage caused by Tenant, its agents, contractors, or invitees and any repair that benefits only the Premises. If any present or future improvements to the Premises are made or authorized to be made by Tenant, its agents or employees, and such improvements shall encroach upon any property or street adjacent to the Premises, or shall violate any agreement or condition contained in any restrictive covenant affecting or applicable to the Premises, or shall impair the rights of others under any easement or right-of-way to which the Premises are subject, then upon request of Landlord, Tenant, at its cost and expense, shall take such action as shall be necessary to remove such encroachments or end such violation or impairment. Notwithstanding the foregoing, Tenant shall not be required to remove any such encroachments if Tenant has or obtains such easements, licenses or similar rights as may be necessary to permit such encroachments to remain.
