Tender Date Sample Clauses

Tender Date. Provided Tenant has delivered to Landlord evidence satisfactory to Landlord that all insurance required to be carried by Tenant and its contractor hereunder is effective, Tenant shall have access to the Premises immediately upon the occurrence of the Tender Date; provided, however, Tenant shall not be entitled to make any alterations or improvements to the Premises until the Tenant’s Plans (as defined in the Work Agreement) have been finally approved by Landlord in accordance with the terms of the Work Agreement. Except for purposes of constructing the Tenant Improvements in accordance with terms of the Work Agreement, Tenant shall not be permitted to occupy the Premises for purposes of conducting its business therein or for any other purpose, unless and until Tenant delivers to Landlord a certificate of occupancy which shall be obtained by Tenant at Tenant’s sole cost and expense. If Landlord notifies Tenant that the Premises are otherwise available for Tenant to take possession thereof, but Tenant is not permitted to take possession of the Premises because Tenant has failed to deliver to Landlord evidence reasonably satisfactory to Landlord that all insurance required hereunder to be carried by Tenant and its contractor is effective, then (a) Landlord shall be deemed to have tendered possession of the Premises to Tenant, (b) neither the Commencement Date nor the Rent Commencement Date shall be delayed as a result thereof, and (c) Tenant shall be entitled to access the Premises when such evidence of insurance has been delivered to Landlord. Between the Tender Date and the day immediately preceding the Rent Commencement Date, all terms and provisions of this Lease shall be in full force and effect, except that Tenant shall not be obligated to pay any (i) Base Rent, or (ii) Additional Rent pursuant to paragraph 3.4, below. Notwithstanding any contrary provision contained in this Lease, in the event the Tender Date has not occurred on or before January 1, 2012 (the “Delay Termination Date”). Tenant shall have the right to terminate this Lease by delivering to Landlord, at any time between the Delay Termination Date and January 31, 2012, at least thirty (30) days prior written notice of such termination; provided, however, in the event the Tender Date occurs on or before the expiration of such thirty (30)-day period, such termination notice shall be deemed to be void and this Lease shall remain in full force and effect as though no termination notice had been...
Sample 1Sample 2
Tender Date. Subject to and in accordance with the terms hereof, Sublandlord shall tender possession of the entire fifth (5th) floor (“Phase 2 Premises”) to the Subtenant on or before April 1, 2011 (the date of such tender, the “Phase 2 Tender Date”).
Sample 1
Tender Date. Landlord shall give Tenant ninety (90) days written notice of the date on which Landlord shall deliver the Property to Tenant (“Tender Date”), which Tender Date is estimated to be November 1, 2009. Tenant shall acknowledge the Tender Date by execution of the Letter of Acceptance, in the form attached as Exhibit “D” hereto.
Sample 1
Tender Date. Subject to and in accordance with the terms hereof, Sublandlord shall tender possession of the entire fourth (4th) floor of the Building (the “Phase 3 Premises”) on or before July 1, 2011 (the “Phase 3 Tender Date”).
Sample 1

Related to Tender Date

  • Payment Date An amount calculated as being due in respect of any Early Termination Date under Section 6(e) will be payable on the day that notice of the amount payable is effective (in the case of an Early Termination Date which is designated or occurs as a result of an Event of Default) and on the day which is two Local Business Days after the day on which notice of the amount payable is effective (in the case of an Early Termination Date which is designated as a result of a Termination Event). Such amount will be paid together with (to the extent permitted under applicable law) interest thereon (before as well as after judgment) in the Termination Currency, from (and including) the relevant Early Termination Date to (but excluding) the date such amount is paid, at the Applicable Rate. Such interest will be calculated on the basis of daily compounding and the actual number of days elapsed.

  • Term Commencement Date A. The date that Sublandlord delivers possession of the Additional Subleased Premises to Subtenant shall be the “Delivery Date.” It is presently anticipated, but not guaranteed, that Sublandlord will deliver possession of the Additional Subleased Premises to Subtenant on or before July 18, 2015 (the “Estimated Delivery Date”). Sublandlord agrees to use commercially reasonable efforts to obtain timely possession of the Additional Subleased Premises from the current occupant. If delivery of possession is delayed or does not otherwise occur by the Estimated Delivery Date, this Second Amendment shall not be void or voidable (except as set forth below), nor shall Sublandlord be liable to Subtenant for any loss or damage resulting therefrom. Notwithstanding anything to the contrary set forth in this Second Amendment, in the event Sublandlord is unable to deliver the Additional Subleased Premises to Subtenant by January 1, 2016, Subtenant shall have the right to terminate this Second Amendment by providing Sublandlord with written notice within ten (10) business days of such date. B. Commencing on the Delivery Date and continuing thereafter until the Additional Subleased Premises Commencement Date (as defined below), Subtenant may access the Additional Subleased Premises solely for the purpose of preparing the Additional Subleased Premises for Subtenant’s occupancy (including the installation of telecommunications wiring, cabling and furniture), without the payment of Base Rent or Additional Rent, provided that all other provisions of the Sublease shall be in full force and effect. C. Subject to the provisions of Section 4.A above, the Term of the Sublease for the Additional Subleased Premises (“Additional Subleased Premises Term”) shall commence on the earlier of (i) forty-five (45) days following the Delivery Date, or (ii) the date that Subtenant commences business operations from the Additional Subleased Premises (the “Additional Subleased Premises Commencement Date”). The Additional Subleased Premises Term shall expire simultaneously with the expiration of the Term for the Original Subleased Premises under the Original Sublease. D. Following the Additional Subleased Premises Commencement Date, Sublandlord may prepare and deliver to Subtenant a commencement letter in the form of Exhibit B attached hereto (the “Commencement Letter”), confirming the Additional Subleased Premises Commencement Date, the Base Rent payable for the Additional Subleased Premises Term and certain other sublease terms with respect to the Additional Subleased Premises. Subtenant shall acknowledge and confirm the Additional Subleased Premises Commencement Date and other sublease terms by executing a copy of the Commencement Letter and returning it to Sublandlord within ten (10) business days after Subtenant’s receipt of the Commencement Letter. If Subtenant fails to sign and return the Commencement Letter to Sublandlord within such ten (10) business day period, the Commencement Letter as sent by Sublandlord shall be deemed to have correctly set forth the Additional Subleased Premises Commencement Date and the other matters addressed in the Commencement Letter. Sublandlord’s failure to send the Commencement Letter shall have no effect on the Additional Subleased Premises Commencement Date.

  • Settlement Date For any Option, the second Business Day immediately following the final Valid Day of the Settlement Averaging Period for such Option.

  • Offer Period The Firm Offer shall be irrevocable for a period (the “Offer Period”) ending at 11:59 P.M., local time at the Company’s principal place of business, on the ninetieth (90th) day following the day of the Offer Notice.

  • Upset Date If the Closing shall not have occurred on or before December 31, 1997.

  • Principal Payment The Borrower shall fail to pay any principal of any Note when the same becomes due and payable as set forth in this Agreement;

  • Call Back Time Any employee called back to work after completion of his/her regular assignment shall be compensated for at least two (2) hours of work at the overtime rate, irrespective of the actual time worked.

  • Acceptance Date The date the Department accepts a Deliverable or System in accordance with Section 7 below shall be deemed the Acceptance Date for each Deliverable or System.

  • Adjustment Date 6 Advance.......................................................................6 Affiliate.....................................................................6 Agreement.....................................................................6

  • Final Maturity Date 19 Fitch .....................................................................................19

Most Referenced Clauses

Most Referenced Definitions