Termination Payment Prior to Commercial Operation Date Sample Clauses

Termination Payment Prior to Commercial Operation Date. (A) If the termination of this Agreement due to a Seller Event of Default occurs before the Commercial Operation Date, then the Termination Payment shall be owed to Buyer and shall be calculated in accordance with Section 7.3(b)(ii). (B) If termination of this Agreement due to a Buyer Event of Default occurs before the Commercial Operation Date then the Termination Payment shall be owed to Seller and shall equal the sum of the actual, documented and verifiable costs incurred by Seller between the Effective Date and the date of termination in connection with the Project, less the fair market value (determined in a commercially reasonable manner) of (1) the individual assets acquired by Seller for the Project, or (2) the entire Project, 10 Note to Bidder – To be determined on a Project-by-Project basis.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Termination Payment Prior to Commercial Operation Date. If the Early Termination Date occurs before the Commercial Operation Date, then the Termination Payment shall be calculated in accordance with this Section 10.3(a). (i) If Owner is the Defaulting Party, then the Termination Payment shall be owed to CHGE and shall equal the Development Security, plus any interest accrued thereon. CHGE shall be entitled to retain all funds held as Development Security and any interest accrued thereon. There will be no amounts owed to Owner. (ii) If CHGE is the Defaulting Party, then the Termination Payment shall be owed to Owner and shall equal the sum of the actual, documented and verifiable costs incurred by Owner between the Effective Date and the Early Termination Date in connection with the Project, less the fair market value (determined in a commercially reasonable manner) of (A) the individual assets acquired by Owner for the Project, or (B) the entire Project, whichever is greater, regardless of whether or not any Owner asset or the entire Project is actually sold or disposed of.
Sample 1Sample 2See All (5)
Termination Payment Prior to Commercial Operation Date. If the Early Termination Date occurs before the Commercial Operation Date, then the Termination Payment shall be calculated in accordance with this Section 10.03(a). (i) If Owner is the Defaulting Party, then the Termination Payment shall be owed to RG&E and shall equal the Development Security, plus any interest accrued thereon. RG&E shall be entitled to retain all funds held as Development Security and any interest accrued thereon. There will be no amounts owed to Owner. (ii) If RG&E is the Defaulting Party, then the Termination Payment shall be owed to Owner and shall equal the sum of the actual, documented and verifiable costs incurred by Owner between the Effective Date and the Early Termination Date in connection with the Project, less the fair market value (determined in a commercially reasonable manner) of (A) the individual assets acquired by Owner for the Project, or (B) the entire Project, whichever is greater, regardless of whether or not any Owner asset or the entire Project is actually sold or disposed of.
Sample 1See All (5)
Termination Payment Prior to Commercial Operation Date. If the Early Termination Date occurs before the Commercial Operation Date, then the Termination Payment shall be calculated in accordance with this Section 10.3(a). If Owner is the Defaulting Party, then the Termination Payment shall be owed to NYSEG and shall equal the Development Security, plus any interest accrued thereon. NYSEG shall be entitled to retain all funds held as Development Security and any interest accrued thereon. There will be no amounts owed to Owner. If NYSEG is the Defaulting Party, then the Termination Payment shall be owed to Owner and shall equal the sum of the actual, documented and verifiable costs incurred by Owner between the Effective Date and the Early Termination Date in connection with the Project, less the fair market value (determined in a commercially reasonable manner) of (A) the individual assets acquired by Owner for the Project, or (B) the entire Project, whichever is greater, regardless of whether or not any Owner asset or the entire Project is actually sold or disposed of.
Sample 1
Termination Payment Prior to Commercial Operation Date. If the Default Termination Date occurs before the Commercial Operation Date, then the Termination Payment shall be calculated in accordance with this Section 10.03(a). (i) If Owner is the Defaulting Party, then the Termination Payment shall be owed to CECONY and shall equal the Development Security, plus any interest accrued on the Development Security, less any Substantial Completion Delay Liquidated Damages previously paid by Owner as of the Default Termination Date. There will be no amounts owed to Owner. (ii) If CECONY is the Defaulting Party, then the Termination Payment shall be owed to Owner and shall equal the sum of the actual, documented and verifiable costs incurred by Owner between the Effective Date and the Default Termination Date in connection with the Project, less the fair market value (determined in a commercially reasonable manner) of (A) the individual assets acquired by Owner for the Project, or (B) the entire Project, whichever is greater, regardless of whether or not any Owner asset or the entire Project is actually sold or disposed of.
Sample 1

Related to Termination Payment Prior to Commercial Operation Date

  • Commercial Operation Date 6.4.1 The SPV shall ensure that the Project Commercial Operation Date is achieved on or prior to the Scheduled Commercial Operation Date. The SPV shall provide a written notice to MSEDCL at least 30 (thirty) days in advance intimating MSEDCL of the proposed date on which the Commercial Operation Date of a Unit or the Project is proposed to be achieved. 6.4.2 If the Commercial Operation Date for the Units having a capacity equivalent to at least 75% (seventy five percent) of the Contracted Capacity is achieved before the Scheduled Commercial Operation Date, then all Units in respect of which the Commercial Operation Date has been achieved prior to the Scheduled Commercial Operation Date would be eligible for incentives as follows: (a) the Unit(s) injecting energy at 11 kV /22 kV shall be given an incentive of Rs. 0.25/ kWh; and (b) the Unit(s) injecting energy at 33 kV shall be given an incentive of Rs. 0.15/ kWh, for the power sold to MSEDCL for the first 3 (three) years from the Commercial Operation Date. To receive such incentives from MSAPL, which shall be over and above the Tariff, the SPV shall follow the process agreed to by the SPV under the Implementation Agreement. 6.4.3 It is hereby clarified that the aforementioned incentive shall not be available: (i) in respect of any Unit if the Commercial Operation Date for such Unit has not been achieved prior to the Scheduled Commercial Operation Date; and (ii) if the aggregate capacity of the Units for which the Commercial Operation Date has been achieved prior to Scheduled Commercial Operation Date is less than 75% (seventy five percent) of the Contracted Capacity. 6.4.4 In the event that Commercial Operation Date for any of the Units is achieved after the Scheduled Commercial Operation Date, the SPV shall be liable to pay Liquidated Damages as per the provisions set out below. 6.4.5 Without prejudice to any other rights of MSEDCL under this PPA, in case one or more Units of the SPV are unable to achieve Commercial Operation Date within a period of 2 (two) months from the Scheduled Commercial Operation Date, the capacity of such Units shall be annulled, and the Contracted Capacity shall be reduced to that extent. For Illustration: The Project has a Contracted Capacity of 100 MW and comprises of 10 Units of 10 MW each. If at the end of the aforementioned period of 14 (fourteen) months from the Effective Date, the SPV has achieved Commissioning for only 8 out of 10 Units, then the Contracted Capacity of the Project will stand reduced for the capacity of the 2 Units which have not been Commissioned, i.e. the Contracted Capacity will be 80 (100 (original Contracted Capacity)) – 10 (capacity of each Unit)*2 (number of Units not Commissioned).

  • Termination Date Determination Seller will not designate the Termination Date (as defined in the Receivables Sale Agreement), or send any written notice to Originator in respect thereof, without the prior written consent of the Agent, except with respect to the occurrence of such Termination Date arising pursuant to Section 5.1(d) of the Receivables Sale Agreement.

  • Commercial Operation (i) On or before December 31, 2021, Interconnection Customer must demonstrate commercial operation of all generating units. Demonstrating commercial operation includes achieving Initial Operation in accordance with Section 1.4 of Appendix 2 to this ISA and making commercial sales or use of energy, as well as, if applicable, obtaining capacity qualification in accordance with the requirements of the Reliability Assurance Agreement Among Load Serving Entities in the PJM Region.

  • Termination Date, Etc “Termination Date” shall mean in the case of the Executive’s death, his date of death, or in all other cases, the date specified in the Notice of Termination subject to the following:

  • Termination Period This Option shall be exercisable for three (3) months after Participant ceases to be a Service Provider, unless such termination is due to Participant’s death or Disability, in which case this Option shall be exercisable for twelve (12) months after Participant ceases to be a Service Provider. Notwithstanding the foregoing sentence, in no event may this Option be exercised after the Term/Expiration Date as provided above and this Option may be subject to earlier termination as provided in Section 13 of the Plan.

  • Post-Termination Cooperation Following any termination of this Agreement, all Parties shall thereafter cooperate fully and work diligently in good faith to achieve an orderly resolution of all matters resulting from such termination.

  • Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.

  • Termination Date For purposes of this Agreement, except as otherwise provided in Section 10(b) and Section 17(a) hereof, the term “Termination Date” means (i) if the Executive’s employment is terminated by the Executive’s death, then the date of death; (ii) if the Executive’s employment is terminated by reason of voluntary early retirement, as agreed in writing by the Company and the Executive, then the date of such early retirement which is set forth in such written agreement; (iii) if the Executive’s employment is terminated by reason of disability pursuant to Section 12 hereof, then the earlier of thirty (30) days after the Notice of Termination is given or one day prior to the end of the Employment Period; (iv) if the Executive’s employment is terminated by the Executive voluntarily (other than for Good Reason), then the date the Notice of Termination is given; and (v) if the Executive’s employment is terminated by the Company (other than by reason of disability pursuant to Section 12 hereof) or by the Executive for Good Reason, then the earlier of thirty (30) days after the Notice of Termination is given or one day prior to the end of the Employment Period. Notwithstanding the foregoing, (A) If termination is by the Company for Cause pursuant to Section 1(d)(iii) of this Agreement and if the Executive has substantially cured the conduct constituting such Cause as described by the Company in its Notice of Termination within such thirty (30) day or shorter period, then the Executive’s employment hereunder shall continue as if the Company had not delivered its Notice of Termination and there shall be no Termination Date arising out of such Notice. (B) If the Company shall give a Notice of Termination for Cause or by reason of disability and the Executive in good faith notifies the Company that a dispute exists concerning such attempted termination within the fifteen (15)-day period following receipt thereof, then the Executive may elect to continue his employment during the pendency of such dispute and the Termination Date shall be determined under this paragraph. If the Executive so elects and it is thereafter determined that Cause or disability (as the case may be) did exist, the Termination Date shall be the earlier of (1) the date on which the dispute is finally determined, either (x) by mutual written agreement of the parties or (y) in accordance with Section 22 hereof, (2) the date of the Executive’s death, or (3) one day prior to the end of the Employment Period. If the Executive so elects and it is thereafter determined that Cause or disability (as the case may be) did not exist, then the employment of the Executive hereunder shall continue after such determination as if the Company had not delivered its Notice of Termination and there shall be no Termination Date arising out of such Notice. (C) If the Executive shall in good faith give a Notice of Termination for Good Reason and the Company in good faith notifies the Executive that a dispute exists concerning such attempted termination within the fifteen (15)-day period following receipt thereof, then the Executive may elect to continue his employment during the pendency of such dispute and the Termination Date shall be determined under this paragraph. If the Executive so elects and it is thereafter determined that Good Reason did exist, the Termination Date shall be the earlier of (1) the date on which the dispute is finally determined, either (x) by mutual written agreement of the parties or (y) in accordance with Section 22 hereof, (2) the date of the Executive’s death or (3) one day prior to the end of the Employment Period. If the Executive so elects and it is thereafter determined that Good Reason did not exist, then the employment of the Executive hereunder shall continue after such determination as if the Executive had not delivered the Notice of Termination asserting Good Reason and there shall be no Termination Date arising out of such Notice. In either case, this Agreement continues, until the Termination Date, if any, as if the Executive had not delivered the Notice of Termination except that, if it is finally determined that Good Reason did exist, the Executive shall in no case be denied the benefits described in Sections 8(b) and 9 hereof (including a Termination Payment) based on events occurring after the Executive delivered his Notice of Termination. (D) Except as provided in Paragraphs (B) and (C) above, if the party receiving the Notice of Termination in good faith notifies the other party that a dispute exists concerning the termination within the fifteen (15)-day period following receipt thereof and it is finally determined pursuant to a legally binding settlement or final and nonappealable judgment or other binding decision that the reason asserted in such Notice of Termination did not exist, then (1) if such Notice was delivered by the Executive, the Executive will be deemed to have voluntarily terminated his employment and (2) if delivered by the Company, the Company will be deemed to have terminated the Executive other than by reason of death, disability or Cause. In the event clause (2) applies, all amounts owed to the Executive under this Agreement shall be paid promptly following the execution of the legally binding settlement or issuance of the final and nonappealable judgment or other binding decision. (E) If the termination is described in Section 2 hereof, then the Termination Date shall be the date of the Executive’s termination of employment from the Company.

  • Term Commencement Date The date that the Premises are Ready For Occupancy (as defined in Exhibit D attached hereto), which Term Commencement Date is anticipated to be August 1, 2015. In the event Landlord fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before November 1, 2015 ("First Outside Date") as such First Outside Date shall be extended due to Force Majeure delays and Tenant Delays, Tenant will be entitled to one day of free Monthly Base Rent, to be applied after the Term Commencement Date, for each day after such First Outside Date that the Premises are not delivered to Tenant as required hereunder. In the event fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before December 1, 2015 ("Second Outside Date"), as such Second Outside Date shall be deemed extended due to Force Majeure delays and Tenant Delays, Tenant may terminate this Lease by delivery of written notice to Landlord no later than that date which is five (5) business days after such Second Outside Date, in which case Landlord will immediately refund all amounts paid by Tenant pursuant to this Lease and Tenant shall have no further obligations to Landlord pursuant to this Lease except for those obligations which expressly survive the expiration or sooner termination of this Lease.

  • Extended Reporting Period If any required insurance coverage is on a claims-made basis (rather than occurrence), Contractor shall maintain such coverage for a period of no less than three (3) years following expiration or termination of the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!