Termination, Suspension and/or Delay of Work Sample Clauses

Termination, Suspension and/or Delay of Work. It is understood and agreed that the City, at its sole option, may change, terminate, delay and/or suspend any and all portions of the covered work at any time. Further, the City may prohibit some or all work on certain days or during certain hours of the day to comply with applicable codes, laws or regulations, permits or to accommodate the ongoing operations of the City’s facilities and/or to mitigate the effect of the ongoing Projects’ work on the businesses and residents in the neighborhood of the Project sites; and/or require such other operational or schedule changes that may be deemed necessary, in its sole judgment, to effectively maintain the primary purpose of the City’s facilities and to remain a good neighbor to the residents and businesses in the area of any Projects. In order to permit the Contractors and Unions to make appropriate scheduling plans, the City will provide the affected Contractor and Union(s) with reasonable notice of any changes it requires pursuant to this Section.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs

Related to Termination, Suspension and/or Delay of Work

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • Termination; Suspension (a) Either Party may terminate this Compact without cause in its entirety by giving the other Party 30 days’ prior written notice. MCC may also terminate this Compact or MCC Funding without cause in part by giving the Government 30 days’ prior written notice. (b) MCC may, immediately, upon written notice to the Government, suspend or terminate this Compact or MCC Funding, in whole or in part, and any obligation related thereto, if MCC determines that any circumstance identified by MCC, as a basis for suspension or termination (as notified to the Government in writing) has occurred, which circumstances include but are not limited to the following: (i) the Government fails to comply with its obligations under this Compact or any other agreement or arrangement entered into by the Government in connection with this Compact or the Program; (ii) an event or series of events has occurred that makes it probable that any of the Project Objectives will not be achieved during the Compact Term or that the Government will not be able to perform its obligations under this Compact; (iii) a use of MCC Funding or continued implementation of this Compact or the Program violates applicable law or United States Government policy, whether now or hereafter in effect; (iv) the Government or any other person or entity receiving MCC Funding or using Program Assets is engaged in activities that are contrary to the national security interests of the United States; (v) an act has been committed or an omission or an event has occurred that would render Nepal ineligible to receive United States economic assistance under Part I of the Foreign Assistance Act of 1961, as amended (22 U.S.C. 2151 et seq.), by reason of the application of any provision of such act or any other provision of law; (vi) the Government has engaged in a pattern of actions inconsistent with the criteria used to determine the eligibility of Nepal for assistance under the MCA Act; and (vii) the Government or another person or entity receiving MCC Funding or using Program Assets is found to have been convicted of a narcotics offense or to have been engaged in drug trafficking.

  • TERM, TERMINATION & SUSPENSION The Company may terminate this Agreement with You at any time for any reason, with or without cause. The Company specifically reserves the right to terminate this Agreement if You violate any of the terms outlined herein, including, but not limited to, violating the intellectual property rights of the Company or a third party, failing to comply with applicable laws or other legal obligations, and/or publishing or distributing illegal material. If You have registered for an account with Us, You may also terminate this Agreement at any time by contacting Us and requesting termination. At the termination of this Agreement, any provisions that would be expected to survive termination by their nature shall remain in full force and effect.

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms. 18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other. 18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1. 18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate. 18.5 Either party may terminate this Agreement immediately, if the other party: (a) commits an irremediable breach; or (b) is subject to a change of control or chooses to discontinue its business; or (c) if the other party has a lack of funding or becomes or is deemed insolvent; or (d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more. 18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you. 18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy. 18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data. 18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you. 18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due. 18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement. 18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.

  • NO CESSATION OF WORK 6.01 Neither the Union nor any employee shall take part in or call or encourage any strike, sit-down, slow-down, or any suspension of work against the Company which shall in any way affect the operations of the Company; nor shall the Company engage in any lockout at its Plants or Mines in the Sudbury District.

  • Suspension; Termination If Borrower voluntarily suspends its business or, the partnership is dissolved or terminated, other than a technical termination of the partnership for tax purposes.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!