The Preliminary Cost Proposal and the Final. Cost Proposal shall each be referred to as a "COST PROPOSAL" and shall collectively be referred to as the "COST PROPOSALS."
The Preliminary Cost Proposal and the Final Sample Clauses
Related to The Preliminary Cost Proposal and the Final
Bidding Phase 2.8.1 The Professional, following the Owner's approval of the Construction Document Phase, shall assist the Owner in obtaining bids and in award and preparation of Construction Contracts. 2.8.2 The Professional shall attend the bid opening and furnish a suitably detailed tabulation sheet for recording the name of each Bidder, the Bidder's Certificate of Responsibility Number, Bid Security, Base Bid, Alternates, and remarks. The Professional shall furnish sufficient tabulation sheets for all in attendance. Immediately after receipt of bids, the Professional shall submit to the Owner a certified tabulation of all bids received, along with his recommendation as to Contract award. 2.8.3 The Professional, following the award of a Construction Contract, shall prepare and submit to the Owner, two (2) copies of updated Construction Documents (Plans/Specifications). Each copy shall be marked OFFICIAL CONTRACT DOCUMENTS and shall include an executed bid Proposal Form, Agreement Form, Contract Bond, Power of Attorney, Certificate of Insurance, all bulletins, Addenda, and supplemental Drawings. One (1) copy shall be retained by the Owner, one (1) copy shall be for the Contractor. Any other contract document guidelines will be distributed to the Professional at the bid opening. 2.8.4 The Professional shall also furnish the area and volume of the building computed in accordance with criteria of the American Institute of Architects; and the square foot and cubic foot costs of only the building, the mechanical system, the electrical system, special built-in equipment, and the total Project cost. 2.8.5 The Professional shall, unless waived by the Owner, also submit one electronic format copy of the updated Contract Documents (plans and specifications) in coordination with said Contract Documents in 2.8.3 above. Said electronic submittal to be submitted within thirty (30) days after award by Owner in .pdf format. The actual cost of the electronic submittal shall be paid by the Owner, with cost approval by the Owner before printing is ordered in accordance with 3.4.
Preliminary Matters 3.1. At least five (5) days prior to the pre-construction meeting described in Section 3.2, Contractor shall submit to Consultant for Consultant’s review and acceptance: 3.1.1. A progress schedule in the indicated form: Bar Chart Modified Critical Path Method (“CPM”) CPM Computerized CPM (CPM is interpreted to be generally as outlined in the Association of General Contractors (“AGC”) publication, “The Use of CPM in Construction.”) The progress schedule shall indicate the start and completion dates of the various stages of the Work, and shall show an activity network for the planning and execution of the Work. Included with the progress schedule shall be a narrative description of the progress schedule. The progress schedule must be updated monthly by Contractor, submitted as part of each Application for Payment, and must be acceptable to Consultant. 3.1.2. A preliminary schedule of Shop Drawing submissions; and 3.1.3. In a lump sum contract or in a contract that includes lump sum bid items of Work, a preliminary schedule of values for all of the Work that includes quantities and prices of items aggregating the Contract Price and that subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include a breakdown of labor, equipment, materials, and an appropriate amount of overhead and profit applicable to each item of Work, which amounts Contractor must confirm in writing at the time of submission. In addition, after award but prior to the submission of the progress schedule, Consultant, Contract Administrator, and Contractor shall meet with all utility owners and secure from them a schedule of utility relocation; provided, however, that neither Consultant nor Town shall be responsible for the nonperformance by the utility owners. 3.2. At a time specified by Consultant, but before Contractor starts the Work at the Project site, a conference attended by Contractor, Consultant, and others as deemed appropriate by Contract Administrator, will be held to discuss the schedules referred to in Section 3.1; to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment; and to establish a working understanding among the Parties as to the Work. 3.3. Within thirty-five (35) days from the Project Initiation Date set forth in the applicable Notice to Proceed, a conference attended by Contractor, Consultant, and others, as appropriate, will be held to finalize the schedules submitted in accordance with Section 3.1. Within forty-five
Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Preliminary Approval Order “Preliminary Approval Order” means the order of the Court preliminarily approving this Settlement Agreement.
Preliminary Approval A. As soon as practicable after this Agreement is fully executed, for settlement purposes only, the Plaintiffs and Co-Lead Counsel shall request the Court to make preliminary findings, enter the Preliminary Approval Order granting conditional certification of the Class, subject to final findings and ratification in the Final Order and Judgment, and appoint the Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class. Neither Defendant nor Defendant’s Counsel will object to such requests for the purposes of effectuating the Settlement. Such agreement not to object to class certification shall extend only as necessary to effectuate the Settlement. As set forth in the draft Preliminary Approval Order, the Plaintiffs shall request the Court to enter an order: 1. preliminarily approving and finding this Agreement and the Settlement as being fair, reasonable, and adequate; 2. conditionally certifying the Litigation as a settlement class action under Rule 23(b)(3) and (e) of the Federal Rules of Civil Procedure; 3. appointing Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class; 4. preliminarily approving the form, manner, and content of the Class Notice, as provided herein, and finding that notice is fair, reasonable, and the best notice practicable under the circumstances in connection with notifying the Class Members of their rights and responsibilities under the Settlement and satisfying due process and Rule 23 of the Federal Rules of Civil Procedure; 5. appointing the Settlement Administrator to send Class Notice and administer the Settlement; 6. providing that Class Members will have until a date certain to object to or file a request for exclusion from the Settlement, as provided herein;
NON-COLLUSIVE BIDDING CERTIFICATE By submission of this bid or proposal, the Bidder certifies that: 1) This bid or proposal has been independently arrived at without collusion with any other Bidder or with any Competitor; 2) This bid or proposal has not been knowingly disclosed and will not be knowingly disclosed, prior to the opening of bids, or proposals for this project, to any other Bidder, Competitor or potential competitor: 3) No attempt has been or will be made to induce any other person, partnership or corporation to submit or not to submit a bid or proposal; 4) The person signing this bid or proposal certifies that he has fully informed himself regarding the accuracy of the statements contained in this certification, and under the penalties being applicable to the Bidder as well as to the person signing in its behalf. Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. You may find the Blank CIQ form on our website at: Copy and Paste the following link into a new browser or tab: xxxxx://xxx.xxxx-xxx.xxx/assets/documents/docs/CIQ.pdf There is an optional upload for this form provided if you have a conflict and must file the form. If you have a conflict of interest as described in this form or the Local Government Code Chapter 176, cited therein- you are required to complete and file with TIPS. Do you have any CONFLICT OF INTEREST TO REPORT OR DISCLOSE under this statutory requirement? YES or NO No If yes (above), have you filed a form CIQ by uploading the form to this RFP as directed above?
Vendor Encouraging Members to bypass TIPS agreement Encouraging entities to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program.
NON-COLLUSIVE BIDDING CERTIFICATION In accordance with Section 139-d of the State Finance Law, if this contract was awarded based upon the submission of bids, Contractor affirms, under penalty of perjury, that its bid was arrived at independently and without collusion aimed at restricting competition. Contractor further affirms that, at the time Contractor submitted its bid, an authorized and responsible person executed and delivered to the State a non-collusive bidding certification on Contractor's behalf.
