Buyer Warranties 38.1 The Buyer represents and warrants that:
(a) it has full power and capacity to enter into this Contract;
(b) it has the financial capacity to perform its obligations;
(c) it does not require the consent of any third party to this Contract or to perform its obligations;
(d) they are aware of the rights given to purchasers by sections 217-219 (inclusive)of the Act ;
(e) that any alteration, variation or matter referred to in clause 13 of this Contract will not materially prejudice their position and the Buyer agrees to be bound by any such matters or alterations;
(f) it has not relied on or been induced to enter into this Contract by any representation or warranty made by the Seller, a consultant of the Seller, an agent of the Seller or any other person other than as expressly set out in this Contract;
(g) it has relied on its own independent investigations and enquiries about the Scheme, the development and the Lot in entering into this Contract;
(h) it has had the opportunity to obtain independent legal, financial, taxation and accounting advice in relation to the Lot and this Contract; and
(i) the Buyer was not introduced to the lot by any person other than the Agent.
38.2 The Buyer agrees that information in brochures, models or other material of any description in connection with the sale of the Lot are indicative only and are not to be relied on or if relied on, the Buyer acknowledges that it elects to do so at its own risk and with full understanding that the Lot and Scheme may vary from the information in those items as represented in any of them, in accordance with the terms of this Contract. Where there is any inconsistency between plans, the sizes, dimensions and measurements on the draft survey plan contained in the Disclosure Statement (as amended from time to time) prevails.
38.3 The Buyer acknowledges and agrees that it has had the opportunity, prior to signing this Contract, to obtain an independent valuation in relation to the Lot and that no representations or warranties about the likely value of the lot at completion has been made by the Seller, a consultant of the Seller, an agent of the Seller.
38.4 The Buyer acknowledges and agrees that it had the opportunity to investigate the Land and the financial viability and/or performance of any investment in the Lot prior to signing this Contract and during the statutory 5 day cooling off period.
Purchaser Warranties 8.1. The Purchaser warrants to the Seller as at the Execution Date, and, save as expressly provided otherwise, as at the Completion Date in terms of the warranties set out in Schedule 4 (“Purchaser Warranties”).
8.2. The Purchaser acknowledges that the Seller has entered into this Agreement in reliance on, amongst others things, the Purchaser Warranties.
8.3. If after the Execution Date (i) it is brought to the knowledge of the Purchaser that any of the Purchaser Warranties were untrue, inaccurate or misleading in any material respect as of the Execution Date, or (ii) any event occurs or any matter arises which to the knowledge of the Purchaser results or could reasonably be expected to result in any of the Purchaser Warranties being untrue, inaccurate or misleading in any material respect at Completion had the Purchaser Warranties been repeated as at the Completion Date, the Purchaser shall notify the Seller in writing as soon as reasonably practicable and in any event prior to the Completion Date. Any such notifications shall be disregarded with respect to determining whether the condition set forth in Clause 3.1(iii) has been satisfied and for the purposes of Clause 10.
Seller Warranties 20.1 The Seller warrants that at the Date of this Contract:
(a) the Seller will be able to complete at Completion;
(b) the Seller has no knowledge of any unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment, order or writ affecting the Land; and
(d) the Seller is not aware of any material change in the matters disclosed in the Housing Development Requirements.
20.2 The Seller warrants that on Completion:
(a) the Seller will have the capacity to complete;
(b) there will be no unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment order or writ affecting the Land; and
(d) the Seller is not aware of any encroachments by or upon the Land except as disclosed. This warranty does not extend to the location of any dividing fence.
20.3 The Seller gives no warranties as to the present state of repair of any of the Improvements or condition of the Land, except as required by law.
Our Warranties We warrant that (i) the Services shall perform materially in accordance with the User Manual, and (ii) the functionality of the Services will not be materially decreased during a Subscription Term. For any breach of either such warranty, Your exclusive remedy shall be as provided in Section 13.3 (Termination for Cause) and Section 13.4 (Refund or Payment upon Termination) below.
Your Warranties You warrant that You have validly entered into this Agreement and have the legal power to do so.
Supplier Warranties The warranties made by Supplier with respect to each Product are solely those that are contained in the product insert accompanying such Product. No other affirmation of fact or promise made by Distributor or its Suppliers, whether or not in this Agreement, by words or action shall constitute a warranty. The foregoing warranty does not extend to any Product that is modified or altered, or treated with abuse, negligence or other improper treatment. Standard Limited Warranty. Distributor shall pass on to Subdistributor so that it may pass on to the customers the Supplier’s standard limited warranty for Products, including limitations set for in subsection (b) Limitation of Liability and Warranty below. Except for the stated warranty set forth on, or included with, the Products as delivered to the Subdistributor and /or its customers, the warranty and remedy set forth in this 0 are exclusive and all other warranties, guarantees or representations, express or implied, by Distributor’s Suppliers with respect to the applicable Products, including, without limitation, warranties of merchantability and fitness for particular purpose, and any other obligation or liability of Distributor and its Suppliers to Subdistributor or to any third party with respect to the Products, are hereby excluded. This warranty is contingent upon proper use of a Product in the application for which such Product was intended and does not cover Products that were modified without Distributor or its Supplier’s prior written approval, that have expired or that were subjected to physical, chemical or electrical stress that the products were not originally designed for.
Customer Warranties Customer warrants that (i) if an entity, it is duly organized and validly existing in good standing; (ii) it is duly authorized to execute, deliver, and perform its obligations under this Agreement; (iii) when duly executed and delivered by each Party, the Agreement will constitute Customer’s legal, valid, and binding obligation, enforceable against it in accordance with its terms; (iv) it is not insolvent and is paying all of its debts as they become due; (v) any payments made pursuant to the Agreement are intended by it to be a substantially contemporaneous exchange for new value given to it; (vi) each payment made of a debt incurred by it under this Agreement is or was in the ordinary course of its business or financial affairs, and (vii) all information supplied by Customer is complete and accurate.
Manufacturer Warranties Prior to the transfer to the Interconnected Transmission Owner of title to the Transmission Owner Interconnection Facilities built by the Interconnection Customer, the Interconnection Customer shall produce documentation satisfactory to the Interconnected Transmission Owner evidencing the transfer to the Interconnected Transmission Owner of all manufacturer warranties for equipment and/or materials purchased by the Interconnection Customer for use and/or installation as part of the Transmission Owner Interconnection Facilities built by the Interconnection Customer.
Seller’s Warranties 10.1 Each of the Sellers warrants to the Buyers, in the terms of the Warranties at the date of this Agreement.
10.2 The Warranties contained in paragraphs 1 to 5, 6.3, 8.3, 10.1, 10.5, 11.1, 13, 17.2 and 18 of Schedule 3 are made of the date hereof and are repeated as of the Completion Date by the Sellers; all other Warranties are made exclusively as of the date hereof.
10.3 The Warranties are qualified by matters fairly disclosed in the Disclosure Letter. In addition to any specific matter disclosed or deemed to be disclosed in accordance with the Disclosure Letter, if and to the extent that the Buyers or any of the directors, officers, employees and/or professional advisers of the Buyers respectively its Affiliates, to the extent they were involved in the investigation of the Company and its business, the evaluation of the Transaction and negotiation of this Agreement, was aware or had notice at any time before the signature of the Agreement of any information relating to the subject matter of the Warranties that could reasonably be expected to put the Buyer on notice of such breach in light of the circumstances, then the Warranties shall be qualified by such information.
10.4 Following the execution of this Agreement but prior to the Completion Date (i) with regard to Warranties listed in Clause 10.2 above the Sellers shall, and (ii) with regard to all other Warranties the Sellers may supplement or amend the Disclosure Letter to reflect matters or circumstances which have arisen after the date hereof. No supplement or amendment to the Disclosure Letter shall be deemed to cure any breach of any Warranty made as of the date of this Agreement or as of the Completion Date, as the case may be. Absent fraud or willful concealment, no failure to supplement or amend the Disclosure Letter in accordance with this Clause 10.4 shall, by itself, constitute a basis for any Claim. Acceptance of any amendment or supplement to the Disclosure Letter shall be without prejudice to the rights of the Buyers to claim for any breach of Warranty made as at the date of this Agreement or as of the Completion Date, as the case may be.
10.5 Where a Warranty is qualified by the expression “so far as the Sellers are aware”, that Warranty shall be deemed to refer to the actual knowledge of the Sellers, the Other Participants, Ixxx Xxxxx, Ixxxx Xxxxxxx, Vxxxxxxxxx Gnasevich, Vxxxxxxx Xxxxxxxx, Vxxxxxxx Xxxxxxxxxx, Txxxxxx Chabunuk, Exxxxxxxx Xxxxxxxx or Julija Didan, not having made any specific inquiries thereto.
10.6 Each of the Warranties shall be construed as a separate and independent warranty and (except where this Agreement provides otherwise) shall not be limited or restricted in its scope by reference to or inference from any other term of another Warranty or this Agreement.
10.7 The Buyers, together with their Representatives, have conducted their own independent investigation of the business of the Company. In entering into this Agreement, the Parties acknowledge that the Buyers are relying on the Warranties set forth in Schedule 3 of this Agreement, and the Buyers.
10.7.1 acknowledge that none of the Sellers, the Company or any of their respective shareholders or Representatives makes or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any of the documents or other information provided or made available to the Buyers or any of its Representatives,
10.7.2 agree, to the fullest extent permitted by law, that none of the Sellers, the Company, any of their shareholders or Representatives shall have any liability or responsibility whatsoever to the Buyers or any of their Representatives on any basis based upon any information provided or made available, or statements made (including in materials furnished in the Data Room, in presentations by the Company’s management or otherwise), to the Buyers or any of their Representatives (or any omissions there from), except that the foregoing limitations shall not apply to any of the Sellers insofar as any such Seller makes the specific Warranties, set forth in Schedule 3 of this Agreement, subject always to the limitations and restrictions contained in Schedule 4.
Vendor’s Warranties CONTRACTOR irrevocably appoints the LEA its agent and attorney-in-fact during the term of this Agreement, so long as the LEA shall not be in default hereunder for the purpose of asserting from time to time whatever claims and rights which CONTRACTOR may have against the Vendor, including warranty claims with respect to the Accepted Buses, but for no other purpose whatsoever. The LEA’s sole remedy for the breach of a warranty shall be against the Vendor and not against CONTRACTOR, nor shall such matters have any effect whatsoever of this Agreement, including the LEA’s obligation to make timely Installment Payments hereunder. The LEA expressly acknowledges that CONTRACTOR makes, and has made, no representation or warranties whatsoever as to the existence or availability of such warranties from the Vendor.
