To be placed on Level 1 General Lists i) Occasional Teachers may select any number of schools for which they will be placed on General Lists.
To be placed on Level 1 General Lists Sample Clauses
Related to To be placed on Level 1 General Lists
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Coverage Types and Policy Limits The types of coverage and policy limits required from the Contractor are specified in Paragraph B Insurance Requirements below.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Grievance Levels Level One. If not resolved on an informal discussion basis, the grievance shall be reduced to writing, outlining:
Offense Level Calculations i. The base offense level is 7, pursuant to Guideline § 2B1.1(a)(1).
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Registry-‐Level Fees (a) Registry Operator shall pay ICANN a registry-‐level fee equal to (i) the registry fixed fee of US$6,250 per calendar quarter and (ii) the registry-‐level transaction fee (collectively, the “Registry-‐Level Fees”). The registry-‐level transaction fee will be equal to the number of annual increments of an initial or renewal domain name registration (at one or more levels, and including renewals associated with transfers from one ICANN-‐accredited registrar to another, each a “Transaction”), during the applicable calendar quarter multiplied by US$0.25; provided, however that the registry-‐level transaction fee shall not apply until and unless more than 50,000 Transactions have occurred in the TLD during any calendar quarter or any consecutive four calendar quarter period in the aggregate (the “Transaction Threshold”) and shall apply to each Transaction that occurred during each quarter in which the Transaction Threshold has been met, but shall not apply to each quarter in which the Transaction Threshold has not been met. Registry Operator’s obligation to pay the quarterly registry-‐level fixed fee will begin on the date on which the TLD is delegated in the DNS to Registry Operator. The first quarterly payment of the registry-‐level fixed fee will be prorated based on the number of calendar days between the delegation date and the end of the calendar quarter in which the delegation date falls.
