RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
Delivery Point The delivery point is the point of delivery of the Power Product to the CAISO Controlled Grid (the “Delivery Point”). Seller shall provide and convey to Buyer the Power Product from the Generating Facility at the Delivery Point. Title to and risk of loss related to the Power Product transfer from Seller to Buyer at the Delivery Point.
Recycled Products The Contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. References: 42 U.S.C. 6962, 40 CFR Part 247, Executive Order 12873 (More than $10,000)
Electricity 14.01 Tenant shall obtain electricity for the Demised Premises on a direct meter basis, Tenant shall be responsible for and pay to the applicable utility all charges for electricity as measured by such meter. Landlord shall not in any way be liable or responsible to Tenant for any loss or damage or expense which Tenant may sustain or incur if either the quantity or character of electric service is changed or is no longer available or suitable for Tenant’s requirements. Any additional riser or risers to supply Tenant’s electrical requirements, upon written request to Tenant, will be installed by Landlord, at the sole cost and expense of Tenant, unless, in Landlord’s reasonable judgment, the same will cause permanent damage or injury to the Building or the Demised Premises or cause or create a dangerous or hazardous condition or interfere with or disturb other tenants or occupants. In addition to the installation of such riser or risers, Landlord will also at the sole cost and expense of Tenant, install all other equipment proper and necessary in connection therewith subject to the aforesaid terms and conditions. Tenant covenants and agrees that at all times its use of electric current shall never exceed the capacity of the feeders to the Building or the risers or wiring installation which Landlord represents is sufficient for ordinary office use. It is further covenanted and agreed by the Tenant that all the aforesaid costs and expenses are chargeable and collectible as Additional Rent and shall be paid by the Tenant to the Landlord within ten (10) days after the rendering of any xxxx or statement to the Tenant therefor. Tenant shall make no alterations or additions to the electric equipment and/or appliances without the prior written consent of Landlord in each instance, which consent shall not be unreasonably withheld, conditioned or delayed. Notwithstanding anything to the contrary herein, should electric service be interrupted for a period of more than five (5) consecutive business days through the sole fault of Landlord so as to prevent Tenant from using at least seventy-five (75%) percent of the Demised Premises, Fixed Rent shall xxxxx until such service resumes and Tenant is able to resume the use of at least seventy-five (75%) percent of the Demised Premises. Should such service interruption prevent Tenant from using at least seventy-five (75%) of the Demised Premises for more than sixty (60) days and be due to the sole fault of Landlord, Tenant shall have the right to terminate this Lease by giving written notice to Landlord no later than the seventieth (70th) consecutive day and vacating no later than the ninetieth (90th) consecutive day. TIME BEING OF THE ESSENCE for Tenant as to both dates. 14.02 Tenant agrees not to connect any additional electrical equipment of any type to the Building electric distribution system, beyond that on Tenant’s approved plans for initial occupancy, other than lamps, computers and other small office machines which consume comparable amounts of electricity, without Landlord’s prior written consent, not to be unreasonably withheld, conditioned or delayed, in each instance. In no event shall Tenant use or install any fixtures, equipment or machines the use of which in conjunction with other fixtures, equipment and machines in the Demised Premises would result in an overload of the electrical circuits servicing the Demised Premises or the Building.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Bidder Supplied Samples The Commissioner reserves the right to request from the Bidder/Contractor a representative sample(s) of the Product offered at any time prior to or after award of a contract. Unless otherwise instructed, samples shall be furnished within the time specified in the request. Untimely submission of a sample may constitute grounds for rejection of Bid or cancellation of the Contract. Samples must be submitted free of charge and be accompanied by the Bidder’s name and address, any descriptive literature relating to the Product and a statement indicating how and where the sample is to be returned. Where applicable, samples must be properly labeled with the appropriate Bid or Contract reference. A sample may be held by the Commissioner during the entire term of the Contract and for a reasonable period thereafter for comparison with deliveries. At the conclusion of the holding period the sample, where feasible, will be returned as instructed by the Bidder, at the Bidder’s expense and risk. Where the Bidder has failed to fully instruct the Commissioner as to the return of the sample (i.e., mode and place of return, etc.) or refuses to bear the cost of its return, the sample shall become the sole property of the receiving entity at the conclusion of the holding period.
Gas If Customer has selected a Gas Fixed Rate, Customer’s Price will be based on the Fixed Rate(s), plus the Administration Charge, set forth in the Application, which includes RITERATE ENERGY’s compressor fuel and transportation charges, administrative and transaction costs and the Gas Balancing Amount and any Regulatory Charges (defined below).
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
Fuel The Vehicle must be returned with the amount of fuel equal to that at the time of the commencement of the rental. If the Vehicle is returned with less fuel, the difference will be charged to You at a rate of $5.00 per litre (which includes a service component).
Delivery Points Project water made available to the Agency pursuant to Article 6 shall be delivered to the Agency by the State at the delivery structures established in accordance with Article 10.
