Site Conditions A. Existing Site Conditions: Information with respect to the site of the Work given in drawings or specifications has been obtained by County's representatives and is believed to be reasonably correct, but the County does not warrant either the completeness or accuracy of such information, and it is the responsibility of the Contractor to verify all such information.
Differing Site Conditions (a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of (1) subsurface or latent physical conditions at the site which differ materially from those indicated in this contract, or (2) unknown physical conditions at the site(s), of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.
(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. Work shall not proceed at the affected site, except at the Contractor’s risk, until the Contracting Officer has provided written instructions to the Contractor. If the conditions do materially so differ and cause an increase or decrease in the Contractor’s cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, the Contractor shall file a claim in writing to the PHA within ten days after receipt of such instructions and, in any event, before proceeding with the work. An equitable adjustment in the contract price, the delivery schedule, or both shall be made under this clause and the contract modified in writing accordingly.
(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in (a) above for giving written notice may be extended by the Contracting Officer.
(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.
Unsafe Conditions In accordance with 29 CFR § 1977, occasions might arise when an employee is confronted with a choice between not performing assigned tasks or subjecting himself/herself to serious injury or death arising from a hazardous condition at the workplace. If the employee, with no reasonable alternative, refuses in good faith to expose himself/herself to the dangerous condition, he/she would be protected against subsequent discrimination. The condition causing the employee's apprehension of death or injury must be of such a nature that a reasonable person, under the circumstances then confronting the employee, would conclude that there is a real danger of death or serious injury and that there is insufficient time, due to the urgency of the situation, to eliminate the danger by resorting to regular statutory enforcement channels. In addition, in such circumstances, the employee, where possible, must also have sought from his Employer, and been unable to obtain, a correction of the dangerous condition.
SUSPENSIVE CONDITIONS 2.1 This entire AGREEMENT is subject to the registration of transfer of ownership of the PROPERTY to the EMPLOYER. In the event that the PROPERTY is not transferred within 6 (six) months from date of signing of this Agreement by the CONTRACTOR, the CONTRACTOR reserves the right to:
2.1.1 increase the CONTRACT SUM, based on the current prices for the building materials, and the CONTRACTOR shall notify the EMPLOYER in writing of such increased cost and the EMPLOYER may then, at his/her option, cancel this agreement by providing written notice of cancellation to the CONTRACTOR within 5 (five) DAYS of receiving written notice from the CONTRACTOR in respect of the increased cost. Should written notice of cancellation not be forthcoming within the aforesaid period, the CONTRACTOR and the EMPLOYER shall proceed with the AGREEMENT at the increased CONTRACT SUM and the EMPLOYER shall be obliged to pay the increase in the CONTRACT SUM to the CONTRACTOR within 21 (twenty one) DAYS of receiving written notice from the CONTRACTOR in respect of the increased cost; or
2.1.2 cancel this AGREEMENT and the parties shall have no claim of whatsoever nature against each other.
2.2 This AGREEMENT is subject further to the EMPLOYER being offered a loan to be secured by a mortgage bond over the PROPERTY and improvements in the amount reflected in Schedule B or such lesser amount as the EMPLOYER may accept, within 30 (thirty) DAYS of the date of the CONTRACTOR’s signature of this AGREEMENT, which period may be extended in the CONTRACTOR’s sole discretion. Should no amount be inserted in the relevant field in the Schedule B, then the suspensive condition contained in this clause will not apply. In the event that the suspensive condition contained in this clause is not fulfilled, this AGREEMENT will lapse and the parties shall have no claim of whatsoever nature against each other.
Service Conditions Customer acknowledges that in the event of a service issue, Customer is responsible for on-site cooperative testing with LightEdge Technical Support to assist in the diagnosis of the trouble. Customer agrees to be bound to current terms of LightEdge Acceptable Use Policy. Terms of the Acceptable Use Policy are subject to change without notice. Current Acceptable Use Policy can be found here: xxxx://xxx.xxxxxxxxx.xxx/legal Customer agrees that any service complaints including concerns regarding level of support, products, service reliability, or any other concerns related to LightEdge or Services being provided by LIghtEdge will be communicated to LightEdge by sending an email to xx@xxxxxxxxx.xxx.
Subsurface Conditions Unless the Contract Documents stipulate specific quantities and units of rock or unsuitable soils, the Contractor shall assume material below the surface of the Earth to be earth and other material that can be removed by power shovel or similar equipment. Should conditions encountered below the surface of the ground be at variance to the number of unit requirements as indicated by drawings or specifications, and absent an agreed-upon unit price established prior to the bid by Addendum, or after contract execution by Change Order, the Contract Sum and/or time shall be adjusted as provided in the Contract Documents for changes in the work.
Adverse Weather Conditions Except in emergency conditions, the Employer shall not require an employee to work outside under extreme weather conditions.
Safe Conditions Whenever an employee reports a condition which the employee feels represents a violation of safety or health rules and regulations or which is an unreasonable hazard to persons or property, such conditions shall be promptly investigated. The appropriate administrator shall reply to the concern, in writing, if the employee's concern is communicated in writing.
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of:
(a) A member of a safety committee; or
(b) A person designated by a safety committee; or
(c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract.
19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days.
19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.
