Billing and Payment; Disputed Amounts 9.1 Except as otherwise provided in this Agreement, each Party shall submit to the other Party on a monthly basis in an itemized form, statement(s) of charges incurred by the other Party under this Agreement.
Disputed Xxxx 2.9.1 If the Buying Entity does not dispute a Monthly Xxxx raised by the other Party within fifteen (15) days of receiving such Xxxx shall be taken as conclusive and binding.
Reimbursable Expenses; Maximum Total Payment; Invoicing District will make no payment until this Contract is fully executed by the authorized representatives of both parties.
Disputed Invoice If Customer disputes any portion of an invoice, Customer must pay the undisputed portion of the invoice and submit a written claim, including all documentation substantiating Customer’s claim, to Comcast for the disputed amount of the invoice by the invoice due date. The Parties shall negotiate in good faith to resolve the dispute. However, should the parties fail to mutually resolve the dispute within sixty (60) days after the dispute was submitted to Comcast, all disputed amounts shall become immediately due and payable to Comcast.
Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must:
Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.
PRORATION PERIOD The Tenant: (check one) ☐ - Shall take possession of the Premises before the start of the Lease Term on , 20 and agrees to pay $ for the proration period. The proration rate is calculated by the monthly Rent on a daily basis which shall be paid by the Tenant upon the execution of this Agreement. ☐ - Shall not be taking possession of the Premises before the Lease Term.
PAYMENT, INVOICING, AUDIT AND TAXES 4.1 All prices are exclusive of VAT or similar taxes and will be in the official currency of the country where the Accenture entity in the Agreement is located.
Interconnection Customer Payments Not Taxable The Parties intend that all payments or property transfers made by the Interconnection Customer to the Participating TO for the installation of the Participating TO's Interconnection Facilities and the Network Upgrades shall be non-taxable, either as contributions to capital, or as a refundable advance, in accordance with the Internal Revenue Code and any applicable state income tax laws and shall not be taxable as contributions in aid of construction or otherwise under the Internal Revenue Code and any applicable state income tax laws.
Disputed Invoices If the Trader or the Distributor disputes a Tax Invoice (which includes a Revision Invoice) issued under this clause 9, the party disputing the invoice ("Disputing Party") must notify the other party ("Non-disputing Party") in writing and provide details as to the reasons why the Disputing Party disputes that invoice within 18 months of the date of the first Tax Invoice issued in respect of the Distribution Services charges the subject of the disputed Tax Invoice ("Invoice Dispute"). On receiving an Invoice Dispute notice, the Non-disputing Party must:
