Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.
Suits by the Corporation The Corporation shall have the right to enforce full payment of the Exercise Price of all Common Shares issued by the Warrant Agent to a Registered Warrantholder hereunder and shall be entitled to demand such payment from the Registered Warrantholder or alternatively to instruct the Warrant Agent to cancel the share certificates and amend the securities register accordingly.
Determinations by the Director All determinations required by the Director under this Agreement are subject to an HSP’s rights of review and appeal under the Act.
Determinations and Actions by the Board of Directors All actions, calculations and determinations (including all omissions with respect to the foregoing) which are done or made by the Board of Directors in good faith pursuant to this Agreement, shall not subject the Board of Directors to any liability to the holders of the Rights.
Verification of Use 20 a. Pursuant to Multnomah County policy, Management must 21 require the completion of a certification form by the employee’s health care provider 22 and any other verifications required for under the provisions of the FMLA, OFLA, or 23 their successors.
CALCULATIONS TO BE MADE BY THIRD PARTY All calculations under this Agreement shall be made annually by an independent third party (the “Third Party”) selected and appointed each year by the District, subject to approval by Applicant in writing, which approval shall not unreasonably be withheld.
Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.
Appointment of Key Sub-Contractors The Supplier shall ensure that all Sub-Contracts contain a provision: requiring the Supplier to pay any undisputed sums which are due from it to the Sub-Contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice; requiring that any invoices submitted by a Sub-Contractor shall be considered and verified by the Supplier in a timely fashion and that undue delay in doing so shall not be sufficient justification for failing to regard an invoice as valid and undisputed; requiring the Sub-Contractor to include in any Sub-Contract which it in turn awards suitable provisions to impose, as between the parties to that Sub-Contract, requirements to the same effect as those required by sub-clauses 5.17.1 and 5.17.2 directly above; and conferring a right to the Customer to publish the Supplier’s compliance with its obligation to pay undisputed invoices within the specified payment period. The Supplier shall pay any undisputed sums which are due from it to a Sub-Contractor within thirty (30) days from the receipt of a valid invoice. Any invoices submitted by a Sub-Contractor to the Supplier shall be considered and verified by the Supplier in a timely fashion. Undue delay in doing so shall not be sufficient justification for the Supplier failing to regard an invoice as valid and undisputed. Notwithstanding any provision of Clauses 9.2 (Confidentiality) and 13 (Publicity, Media and Official Enquiries) if the Supplier notifies the Customer that the Supplier has failed to pay an undisputed Sub-Contractor’s invoice within thirty (30) days of receipt, or the Customer otherwise discovers the same, the Customer shall be entitled to publish the details of the late or non-payment (including on Government websites and in the press).
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
Compensation for default by the Concessionaire Subject to the provisions of Clause 35.6, in the event of the Concessionaire being in material default or breach of this Agreement, it shall pay to the Authority by way of compensation, all direct costs suffered or incurred by the Authority as a consequence of such material default or breach, within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no compensation shall be payable under this Clause 35.1 for any material breach or default in respect of which Damages are expressly specified and payable under this Agreement.