Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Payment of Other Taxes by the Credit Parties The Credit Parties shall timely pay to the relevant Governmental Authority in accordance with Applicable Law, or at the option of the Administrative Agent timely reimburse it for the payment of, any Other Taxes.
Payments and Computations, Etc (a) All amounts to be paid or deposited by the Seller or the Servicer hereunder or under any other Transaction Document shall be made without reduction for offset or counterclaim and shall be paid or deposited no later than noon (New York, New York time) on the day when due in same day funds to the account for each Purchaser maintained by the applicable Purchaser Agent as may be designated from time to time by such Purchaser Agent to the Seller and the Servicer. All amounts received after 1:00 p.m. (New York, New York time) will be deemed to have been received on the next Business Day. Except as expressly set forth herein, each Purchaser Agent shall distribute the amounts paid to it hereunder for the benefit of the Purchasers in its Purchaser Group to the Purchasers within its Purchaser Group ratably (x) in the case of such amounts paid in respect of Discount and fees, according to the Discount and fees payable to such Purchasers and (y) in the case of such amounts paid in respect of Capital (or in respect of any other obligations other than Discount and fees), according to the outstanding Capital funded by such Purchasers.
(b) The Seller (with respect to amounts payable by the Seller) or the Servicer (with respect to amounts payable by the Servicer), as the case may be, shall, to the extent permitted by law, pay interest on any amount not paid or deposited by the Seller or the Servicer, as the case may be, when due and payable hereunder, at an interest rate equal to 2.00% per annum above the Base Rate, payable on demand; provided, that such rate shall not at any time exceed the maximum rate permitted by applicable Law.
(c) All computations of interest under clause (b) and all computations of Discount, fees and other amounts hereunder shall be made on the basis of a year of 360 days (or 365 or 366 days, as applicable, with respect to Discount or other amounts calculated by reference to the Base Rate) for the actual number of days elapsed. Whenever any payment or deposit to be made hereunder shall be due on a day other than a Business Day, such payment or deposit shall be made on the next Business Day and such extension of time shall be included in the computation of such payment or deposit.
Reasonable and Continuing Obligations Executive agrees that Executive’s obligations under this Section 6 are obligations which will continue beyond the date Executive’s employment terminates and that such obligations are reasonable, fair and equitable in scope. The terms and duration are necessary to protect the Company’s legitimate business interests and are a material inducement to the Company to enter into this Agreement. Executive further acknowledges that the consideration for this Section 6 is his employment or continued employment. Executive will not be paid any additional compensation during this Restricted Period for application or enforcement of the restrictive covenants contained in this Section 6.
Compliance of Agreement, Loan Documents and Borrowing with Laws, Etc The execution, delivery and performance by each Credit Party of the Loan Documents to which each such Person is a party, in accordance with their respective terms, the Extensions of Credit hereunder and the transactions contemplated hereby or thereby do not and will not, by the passage of time, the giving of notice or otherwise, (a) require any Governmental Approval or violate any Applicable Law relating to any Credit Party where the failure to obtain such Governmental Approval or such violation could reasonably be expected to have a Material Adverse Effect, (b) conflict with, result in a breach of or constitute a default under the articles of incorporation, bylaws or other organizational documents of any Credit Party, (c) conflict with, result in a breach of or constitute a default under any indenture, agreement or other instrument to which such Person is a party or by which any of its properties may be bound or any Governmental Approval relating to such Person, which could, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, (d) result in or require the creation or imposition of any Lien upon or with respect to any property now owned or hereafter acquired by such Person other than Permitted Liens or (e) require any consent or authorization of, filing with, or other act in respect of, an arbitrator or Governmental Authority and no consent of any other Person is required in connection with the execution, delivery, performance, validity or enforceability of this Agreement, other than (i) consents, authorizations, filings or other acts or consents previously obtained or for which the failure to obtain or make could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect and (ii) consents or filings under the UCC or other security filings.
Cooperation of Borrower If necessary, Borrower agrees to (i) execute any documents (including new Secured Promissory Notes) reasonably required to effectuate and acknowledge each assignment of a Term Loan Commitment or Loan to an assignee in accordance with Section 12.1, (ii) make Borrower’s management available to meet with Collateral Agent and prospective participants and assignees of Term Loan Commitments or Credit Extensions (which meetings shall be conducted no more often than twice every twelve months unless an Event of Default has occurred and is continuing), and (iii) assist Collateral Agent or the Lenders in the preparation of information relating to the financial affairs of Borrower as any prospective participant or assignee of a Term Loan Commitment or Term Loan reasonably may request. Subject to the provisions of Section 12.9, Borrower authorizes each Lender to disclose to any prospective participant or assignee of a Term Loan Commitment, any and all information in such Lender’s possession concerning Borrower and its financial affairs which has been delivered to such Lender by or on behalf of Borrower pursuant to this Agreement, or which has been delivered to such Lender by or on behalf of Borrower in connection with such Lender’s credit evaluation of Borrower prior to entering into this Agreement.
Verification of Coverage Prior to beginning any work under this Agreement, Consultant shall furnish City with certificates of insurance and with original endorsements effecting coverage required herein. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The City reserves the right to require complete, certified copies of all required insurance policies at any time.
Payment of Other Taxes by the Borrowers Without limiting the provisions of subsection (a) above, each Borrower shall timely pay any Other Taxes to the relevant Governmental Authority in accordance with applicable law.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Payment of Other Taxes by Loan Parties The Loan Parties shall timely pay to the relevant Governmental Authority in accordance with applicable law, or at the option of the Administrative Agent timely reimburse it for, Other Taxes.
