Warranty claims with regard to subscription licenses Sample Clauses

Warranty claims with regard to subscription licenses. 6.7.1 PTC will provide and maintain the subscription licenses in a suitable condition for the contractual use (“fitness for contractual use”). The maintenance of the subscription licenses’ fitness for contractual use will be provided by way of Support Services in accordance with the terms and conditions for Support Services as set out under xxxx://xxxxxxx.xxx.xxx/support/services/support-policies/, such Support Services being included with the purchase of subscription licenses without additional fee. The obligation to maintain the Licensed Products does not include adjustments to changes in operating conditions or the IT environment, in particular to changes in hardware or operating systems or to new file formats. 6.7.2 In the event of an Error as defined in Schedule B affecting a Licensed Product’s fitness for contractual use, PTC at its sole discretion may (a) replace the Licensed Product(s) that contains the Error or (b) repair the Error, provided that the notice of the Error is received by PTC promptly after discovery of such Error by Customer and Customer provides such additional information regarding the Error as PTC reasonably requests. If the repair (either by providing a bug fix, a workaround or otherwise) or replacement fails finally (after at least two attempts for the same Error from the side of PTC within reasonable periods of time), Customer shall be entitled, at Customer's choice, to (a) a termination of the Licensed Product(s) containing the Error so that PTC provides a refund of the prepaid subscription fees for the remainder of the subscription term for the Licensed Product(s) containing the Error upon return of such Licensed Product(s) and any copies made thereof or (b) a reasonable reduction in the subscription fee of the respective Licensed Product(s). Replacements or repairs shall be made without acknowledgement of a legal obligation and shall not suspend the limitation period for warranty claims related to the Licensed Products. 6.7.3 PTC's liability for damages without fault (verschuldensunabhängige Haftung) for defects that existed upon PTC’s acceptance of an order is excluded. 6.7.4 The Customer's right to terminate for deprivation of use in accordance with section 543 para.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs

Related to Warranty claims with regard to subscription licenses

  • Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim

  • Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.

  • Contract (Rights of Third Parties) Xxx 0000 22.1 No person who is not a party to this Grant Agreement shall have the right to enforce any of its terms.

  • Paid Claims without Supporting Documentation Any Paid Claim for which Xxxxxxx cannot produce documentation shall be considered an error and the total reimbursement received by Xxxxxxx for such Paid Claim shall be deemed an Overpayment. Replacement sampling for Paid Claims with missing documentation is not permitted.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights. 29.2. The Contractor must promptly notify the Authority if any claim or demand is made or action brought against the Contractor for infringement or alleged infringement of any Intellectual Property Right which may affect the use or possession of the Deliverables or which may affect the provision of the Services. 29.3. Where a claim to which this clause applies is made, the Contractor must, at its expense, use its best endeavours to: 29.3.1. modify the Services or Deliverables or substitute alternative Services or Deliverables (in any case without reducing performance or functionality) so as to avoid the infringement or alleged infringement of the Intellectual Property Rights; or 29.3.2. procure the grant of a licence or licences from the pursuer, claimant or complainer, on terms acceptable to the Authority, so as to avoid the infringement or alleged infringement of the Intellectual Property Rights of the pursuer, claimant or complainer. 29.4. The Contractor must not without the consent of the Authority make any admissions which may be prejudicial to the defence or settlement of any claim to which this clause applies.

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Pursuit of Claims Against Third Parties If (i) a Party incurs any Liability arising out of this Agreement or any Ancillary Agreement; (ii) an adequate legal or equitable remedy is not available for any reason against the other Party to satisfy the Liability incurred by the incurring Party; and (iii) a legal or equitable remedy may be available to the other Party against a Third Party for such Liability, then the other Party shall use its commercially reasonable efforts to cooperate with the incurring Party, at the incurring Party’s expense, to permit the incurring Party to obtain the benefits of such legal or equitable remedy against the Third Party.

  • Certain Additional Actions Regarding Intellectual Property If any Event of Default shall have occurred and be continuing, upon the written demand of the Collateral Agent, each Pledgor shall execute and deliver to the Collateral Agent an assignment or assignments of the registered Patents, Trademarks and/or Copyrights and Goodwill and such other documents as are necessary or appropriate to carry out the intent and purposes hereof. Within five (5) Business Days of written notice thereafter from the Collateral Agent, each Pledgor shall make available to the Collateral Agent, to the extent within such Pledgor’s power and authority, such personnel in such Pledgor’s employ on the date of the Event of Default as the Collateral Agent may reasonably designate to permit such Pledgor to continue, directly or indirectly, to produce, advertise and sell the products and services sold by such Pledgor under the registered Patents, Trademarks and/or Copyrights, and such persons shall be available to perform their prior functions on the Collateral Agent’s behalf.

  • Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!