Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Act of God Landlord shall not be required to perform any covenant or obligation in this Lease, or be liable in damages to Tenant, so long as the performance or non-performance of the covenant or obligation is delayed, caused or prevented by an act of God, force majeure or by Tenant.
Strikes Nothing in this Agreement permits or grants to any employee the right to strike or refuse to perform their official duties.
STRIKES & LOCKOUTS The Union agrees there shall be no strikes and the Hospital agrees there shall be no lockouts so long as this Agreement continues to operate. The terms "strike" and "
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
Sabotage Sabotage is of concern to all Parties involved on any work site and may affect safety, and therefore both the physical and mental well being of all persons on site. The Parties to this Agreement will not tolerate sabotage, and will ensure that any person/s responsible for such action is immediately dismissed. It is accepted that the relevant authorities may have to be notified, and provisions of the OH&S Act implemented.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.
Inclement Weather 24.1 This Inclement Weather clause sets out the full rights, obligations and entitlements of the parties and establishes the conditions under which payment for periods of inclement weather shall be made. 24.2 This Inclement Weather clause is to be read and observed in lieu of the provisions of the award and VBIA. 24.3 Definition – inclement weather Inclement weather shall mean the existence of rain or abnormal climatic conditions (whether they be those of hail, snow, cold, high wind, severe dust storm, extreme high temperature or the like or any combination thereof) by virtue of which it is either not reasonable or not safe for employees exposed thereto to continue working whilst the same prevail.
STRIKES OR LOCKOUTS 5.01 During the term of this Agreement, or while negotiations for a further agreement are being held the Union will not permit or encourage any strike, slowdown, or any stoppage of work or otherwise restrict or interfere with the Employer's operation through its members. 5.02 During the term of this Agreement, or while negotiations for a further agreement are being held, the Employer will not engage in any lockout of its employees or deliberately restrict or reduce the hours of work.
