Without prejudice to the generality of Clause 10.1, GO Power shall, in relation to any Personal Data processed in connection with the performance by GO Power of its obligations under this Agreement:
(a) process that Personal Data only on the written instructions of the Customer unless GO Power is required by the laws of any member of the European Union or by the laws of the European Union applicable to GO Power to process Personal Data (Applicable Data Processing Laws). Where GO Power is relying on laws of a member of the European Union or European Union law as the basis for processing Personal Data, GO Power shall promptly notify the Customer of this before performing the processing required by the Applicable Data Processing Laws unless those Applicable Data Processing Laws prohibit GO Power from so notifying the Customer;
(b) process that Personal Data only to the extent necessary for the legitimate interest of GO Power and its specified third parties, and as required for the performance of this Agreement and the rights of GO Power under it;
(c) ensure that it has in place appropriate technical and organisational measures to protect against unauthorised or unlawful processing of Personal Data and against accidental loss or destruction of, or damage to, Personal Data, appropriate to the harm that might result from the unauthorised or unlawful processing or accidental loss, destruction or damage and the nature of the data to be protected, having regard to the state of technological development and the cost of implementing any measures (those measures may include, where appropriate, pseudonymising and encrypting Personal Data, ensuring confidentiality, integrity, availability and resilience of its systems and services, ensuring that availability of and access to Personal Data can be restored in a timely manner after an incident, and regularly assessing and evaluating the effectiveness of the technical and organisational measures adopted by it);
(d) ensure that all personnel who have access to and/or process Personal Data are obliged to keep the Personal Data confidential;
(e) not transfer any Personal Data outside of the European Economic Area unless the consent of the Customer has been obtained and the following conditions are fulfilled:
(i) the Customer or GO Power has provided appropriate safeguards in relation to the transfer;
(ii) the data subject has enforceable rights and effective legal remedies;
(iii) GO Power complies with its obligations under the Data Protection Legislation by providing an adequate level of protection to any Personal Data that is transferred; and
(iv) GO Power complies with reasonable instructions notified to it in advance by the Customer with respect to the processing of the Personal Data;
(f) assist the Customer, at the Customer’s cost, in responding to any request from a Data Subject and in ensuring compliance with its obligations under the Data Protection Legislation with respect to security, breach notifications, impact assessments and consultations with supervisory authorities or regulators;
(g) notify the Customer without undue delay on becoming aware of a Personal Data breach; AND
(h) at the written direction of the Customer, delete or return Personal Data and copies thereof to the Customer on termination of the Agreement unless required by Applicable Data Processing Law to store the Personal Data;
Without prejudice to Paragraph 6.1, University’s liability to the Licensee for all losses or damage of any kind howsoever caused shall be limited to the aggregate total amount received by University from Licensee under this Agreement as at the date of such breach.
Without prejudice to Clause 10.1 above, this Clause shall remain in full force and effect notwithstanding any discharge, release or termination of this Pledge (whether or not in accordance with Clause 7.1 of this Pledge Agreement).
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.
Without prejudice all proceedings and disclosures will be conducted and made without prejudice to the rights and positions of the parties in any subsequent arbitration or other legal proceedings;
Obligations of the Service Provider 3.1. The Service Provider undertakes to provide the services as set out online within the dedicated Hoople Schools portal to this Agreement (the ‘Services’), in consideration of the payment as set out in the dedicated Hoople Schools portal. The Service Provider has undertaken Payment calculation based on the following terms:
3.1.1. payment for services relating to employee numbers has been calculated based on the number of employees at each Establishment as at January 2020. Included in the calculation is a 5% tolerance. If employee numbers rise above this 5% tolerance Hoople reserves the right to charge incremental fees
3.1.2. payment for the Payments Management service has been based on the number of payment vouchers raised in 2018/19, within a 10% tolerance level. The Service Provider reserves the right to increase pricing if volumes increase by more than the stated tolerance level
3.1.3. should the Establishment request an additional service during the duration of the term, the Service Provider reserves the right to charge the full, annual cost of the requested service
3.1.4. payment for services relating to pupil numbers has been calculated based on the number of pupils at each Establishment as at October 2019. Included in the calculation are sixth form and nursery pupil numbers, where applicable
3.1.5. The Service Provider will provide digital order confirmation of the services ordered and associated fees by means of the functionality of the Hoople Schools portal
3.2. Should the Establishment request and the Service Provider agrees to provide services additional to those specified within the schools buying portal order, the fees for those additional services shall be mutually agreed between the parties, but otherwise for all purposes of this Agreement, the additional services shall be deemed to be included within the definition of Services.
3.3. The Services shall be carried out by the Service Provider with all reasonable skill and care, and in full compliance of relevant established current professional standards. The Service Provider undertakes to provide a detailed service level agreement (SLA), outlining the responsibilities of both parties with regard to each service. The SLA for each service will be provided as a downloadable document on the Hoople Schools portal.
3.4. The Service Provider shall indemnify the Establishment from all claims, actions or demands made by third parties against the Establishment, and all liabilities of the Establishment to third parties (collectively ‘Third Party Liabilities’) and from all damage, losses, costs, expenses and payments whatsoever suffered or incurred by the Establishment either directly or in relation to Third Party Liabilities in respect of (a) personal injury to or the death of any person and any loss or destruction of or damage to property (not attributable to any default or neglect of the Establishment or of any person for whom the Establishment is responsible) which shall have occurred in connection with the provision of the Services under this Agreement, (b) any defect in the Services, and (c) any breach by the Service Provider of any terms of this Agreement, including without limitation, clause
Without prejudice to Sections 5.1 and 5.2 above, You are responsible for (a) any required notices, consents and/or authorizations related to Your provision of, and our processing of, Your Content (including any Personal Data) as part of the Services, (b) any security vulnerabilities, and the consequences of such vulnerabilities, arising from Your Content, including any viruses, Trojan horses, worms or other harmful programming routines contained in Your Content, and (c) any use by You or Your Users of the Services in a manner that is inconsistent with the terms of this Agreement. To the extent You disclose or transmit Your Content to a third party, we are no longer responsible for the security, integrity or confidentiality of such content outside of Oracle’s control.
Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.
Without Prejudice or Precedent The parties to the Committee agree that any discussion at the Committee will be on a without-prejudice and without-precedent basis, unless agreed otherwise.
