Cold Shell definition

Cold Shell means an unfinished interior lacking heating, ventilating, and air conditioning (commonly known as HVAC); lighting; plumbing; ceilings; elevators; and interior walls, but that includes connections to the HVAC, plumbing and other building systems.
Sample 1Sample 2Sample 3
Cold Shell as defined in Exhibit "C." Lessee shall take good care of the Premises. Lessee may make alterations in and to the Premises and building thereon, only upon prior written approval of Lessor which approval shall not be unreasonably withheld. All repairs and alterations shall be in quality at least equal to the original construction. At the termination of this Lease, Lessee shall deliver the Premises to Lessor in as good condition as when delivered to Lessee, reasonable wear and tear, changes and alterations authorized under this Lease, loss and damage by fire or other casualty excepted.
Sample 1
Cold Shell means those portions of the Building and the associated site Improvements on the Land (such as driveways, parking areas, landscaping and exterior lighting) that are specified on Exhibit B.
Sample 1

Examples of Cold Shell in a sentence

  • The Community Facilities Space shall be provided by Vertical Developer to the Approved Community Facilities Entity in Cold Shell condition and on the same general terms and conditions as are provided to other similar Community Facilities Entities for other similar Community Facilities Space within the Project and as are provided to other users within the Sub- Phase and Major Phase of which the Community Facilities Space is a part, subject to the provisions set forth below.

  • If parties agree to execute the CMA for Cold Shell Building improvements (within two weeks of Lease Agreement execution) then Date of Delivery shall be deemed as the date when Cold Shell Building and Improvements is delivered to Tenant.

  • If delivery of Cold Shell Building to Tenant by Landlord is delayed more than three months after the original delivery date, Tenant shall have the right to terminate the Lease Agreement.

  • Parties have agreed to exclude from "Substantial Completion" scope of work the concrete floor of the Cold Shell Building due to construction strategy; as a result a total of US$104,000.00 will be credited in favor of the Tenant into the Improvements Construction Management Agreement to be executed among parties.

  • The Landlord will deliver a Substantially Completed (as defined in Clause 1.07 above) Cold Shell Building to Tenant no later than November 30th, 2015 provided the execution date of this Lease Agreement takes place before August 7th, 2015.

  • The Premises will be as of the date delivered to Tenant in good working order and condition, including without limitation, the Cold Shell Building and plumbing system are brand new, the roof free of leaks and that they have been built and/or installed as per Construction Code, Equipment and Systems Manufacturer instructions and all applicable laws of Costa Rica; as a result the Premises, its systems and equipment are covered by the guarantee terms established in the applicable Costa Rican laws.

  • Exhibit Three: Cold Shell Building Description Exhibit Four: a) Condominium By-laws and b) Park Regulations.

  • CFZ is interested in completing all improvements to the Cold Shell Building activities at the sole cost and expense of ESTABLISHMENT as per the Design, Architecture & Engineering and Build-Out Construction Management Agreement.

  • ESTABLISHMENT will receive a credit from ZFC for a total amount of US$104,400.00 in relation to the concrete floor of the Cold Shell Building Lease Agreement scope of work; construction of the concrete floor is currently included within this Agreement.

  • After the Cold Shell Building is Substantially Completed, or, in the event the Improvements CMA is executed between the Tenant and Landlord, after the Cold Shell Building Improvements are Substantially Completed, Tenant will provide Landlord the security deposit mentioned above in cash if such security deposit was provided to Landlord through a local bank guarantee at the execution of this Lease Agreement.

Related to Cold Shell

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.

  • Load Shedding means the systematic reduction of system demand by temporarily decreasing load in response to transmission system or area capacity shortages, system instability, or voltage control considerations under Tariff, Part II or Part III.

  • Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Systems Engineering means preparing specifications, identifying and resolving interface problems, developing test requirements, evaluating test data, and supervising design.

  • Construction Consultant means a third-party architect or engineer selected and retained by Funding Lender, at the cost and expense of Borrower, to monitor the progress of construction and/or rehabilitation of the Project and to inspect the Improvements to confirm compliance with this Borrower Loan Agreement.

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Architect/Engineer means the person designated by the Commissioner to provide the Contract drawings and Detailed Specifications for the Work you are to perform.

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • Construction Phase Services means the coordination, implementation and execution of the Work required by this Agreement, which are further defined in Article 8.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Fabrication means making up data or results and recording or reporting them.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Engineering means the application of scientific knowledge for the design, control, or use of building structures, equipment, or apparatus.

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • construction site means a workplace where construction work is being performed;

  • Architectural coating means a coating applied to stationary structures and their appurtenances, to mobile homes, to pavements, or to curbs.

  • Construction Management Agreement means the Construction Management Agreement, dated as of the date of the Common Agreement, between Construction Manager and the Project Company.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Backflow Prevention Assembly means any mechanical assembly installed at a water service line or at a plumbing fixture to prevent a backflow contamination event, provided that the mechanical assembly is appropriate for the identified contaminant at the cross connection and is an in-line field-testable assembly.

  • Structural Engineer means the Engineer appointed or to be appointed from time to time by Promoter for the preparation of the structural design and drawings of the buildings .

  • Commissioning Date means that date when construction of the contemplated Project is complete, and the Maintenance Term commences;

  • Turnkey means a procurement process where one service provider assumes total responsibility for all aspects of the project and delivers the full end product / service required by the contract.