Completion of Wave 2 definition

Completion of Wave 2 means the achievement of the Wave 2 Success Criteria as defined under the Technology Transfer Plan.
Sample 1Sample 2Sample 3
Completion of Wave 2 means achievement of all the “Wave 2 Milestone Success Criteria” as defined under the Technology Transfer Plan.
Sample 1Sample 2

Examples of Completion of Wave 2 in a sentence

  • The Technology Transfer will be deemed complete upon the Completion of Wave 1 and the Completion of Wave 2.

  • The Technology Transfer will be deemed complete upon the Completion of Wave 1, the Completion of Wave 2 and the Completion of Wave 3.

  • If Merck terminates this Agreement pursuant to this Section 12.4 prior to receipt by Codexis of the Milestone Payment associated with the Completion of Wave 2 as contemplated by Section 7.3, in addition to the provisions of Section 12.6.2, Merck shall pay to Codexis the applicable termination payment set forth in this Section 12.4. [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission.

  • Completion and/or success of Evolution Programs is not a condition to the Completion of Wave 1 or the Completion of Wave 2.

  • Execution Version Affiliates and/or Third Parties controlled by Merck and/or its Affiliates, the applicable milestone payment(s) set forth in Section 7.3 shall be paid to Codexis in the manner set forth in Section 7.3. In the event either Party reasonably disputes whether or not the Completion of Wave 1 and/or the Completion of Wave 2 have occurred, the Parties will submit such dispute for resolution in accordance with Article 13.

  • If Novartis terminates this Agreement pursuant to this Section 12.4 after the receipt by Codexis of the Milestone Payment associated with the Completion of Wave 2 but prior to receipt by Codexis of the Milestone Payment associated with the Completion of Wave 3 as contemplated by Section 7.2, in addition to the provisions of Section 12.5.2, Novartis shall pay to Codexis the sum of $5,000,000.00.

  • If Completion of Wave 1 and/or the Completion of Wave 2 are not achieved on or before [***] from the Effective Date where such non-achievement is proximately caused by decision(s), action(s) or inaction(s) of Merck, its [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission.

  • If Merck terminates this Agreement pursuant to this Section 12.4 prior to receipt by Codexis of the Milestone Payment associated with the Completion of Wave 2 as contemplated by Section 7.3, in addition to the provisions of Section 12.6.2, Merck shall pay to Codexis the applicable termination payment set forth in this Section 12.4.

Related to Completion of Wave 2

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion of Services means..................................................

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Completion of Construction means the date, as determined by the Division after consultation with the Recipient, that the work of building and erection of the Project is substantially complete.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Completion means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract.

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Construction Work means any work in connection with⎯

  • Improvement completion assurance means a surety bond, letter of credit,

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.