Connection Works Completion Date definition

Connection Works Completion Date means the date on which the Company is satisfied that the Connection Works have been completed to the extent necessary to allow all Commissioning Tests to be performed;
Sample 1Sample 2Sample 3

Examples of Connection Works Completion Date in a sentence

  • If the Independent Engineer determines that the Connection Works were so completed on a date other than the date specified in the Company's notification, then the date so determined by the Independent Engineer shall be the Connection Works Completion Date.

  • The Company shall, as soon as it is satisfied that the Connection Works Completion Date is reached, notify the Customer to that effect specifying the date on which such completion occurred.

  • Without limiting the other provisions of this Paragraph 4, to the extent that each Party has not done so already, each Party shall commence its Commissioning Tests and proceed to carry them out in accordance with the Connection Agreement, forthwith after the Connection Works Completion Date.

  • The Customer agrees to convey to ESB, for a nominal sum of €1 a freehold interest (if the Customer does not own the freehold, a leasehold interest for a period of not less than 100 years) in those components of the Connection Works as identified in the Offer Letter on or before the Connection Works Completion Date.

  • Without limiting the other provisions of this Paragraph 4, to the extent that each Party has not done so already, each Party shall commence its Commissioning Tests and proceed to carry them out in accordance with the Connection Agreement forthwith after the Connection Works Completion Date.

  • The Company shall, as soon as it is satisfied that the Connection Works Completion Date is reached, notify the Customer to that effect specifying thedate on which such completion occurred.

  • DSO responseThe DSO proposed providing a programme with the connection offer, which would be updated at the 55% stage, setting out the work-streams and the critical path to achieving the Connection Works, Completion Date and the Operational Date.

  • DSO will provide an updated programme (in Gantt chart format) setting out the work-streams and the critical path to achieving the Connection Works Completion Date and the Operational Date.

  • As part of the connection offer DSO will provide the following information to the developer: • An outline programme (in Gantt chart format) setting out the work- streams and the critical path to achieving the Consents Issue Date, Connection Works Completion Date and Operational Date.

  • Without limiting the other provisions of this Paragraph 4, to the extent that each Party has not done so already, each Party shall commence itsthe Commissioning Tests as agreed between the Parties and proceed to carry them out in accordance with the Connection Agreement, forthwith after the Connection Works Completion Date.

Related to Connection Works Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Final Completion Date means the date on which Final Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.

  • Construction Work means any work in connection with⎯

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • construction site means a workplace where construction work is being performed;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Excavation work means the making of any man-made cavity, trench, pit or depression formed by cutting, digging or scooping;

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Installation Works means, as the context so requires,

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Generation Interconnection Feasibility Study means a study conducted by the Transmission Provider (in coordination with the affected Transmission Owner(s)) in accordance with Tariff, Part IV, section 36.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;