If the Maturity Date is extended in accordance with this Section 3.19(b), all references to the Original Maturity Date, the First Extended Maturity Date, or the Second Extended Maturity Date shall be interpreted so that such references are to such date, as extended by the applicable Force Majeure Extension Period.
Force Majeure Period has the meaning specified in Section 13.1.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);
Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.
Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.
Force Majeure Failure has the meaning set forth in Section 8.1(d).
Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;
Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.
Event of Force Majeure means one of the following events:
Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and
Service Extension shall have the meaning set forth in Section 7.1(c).
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
First Extension Period means a period of twelve (12) consecutive months following the Initial Maturity Date.
Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Rectification Period means the period of time set out in Section 4.3 of this RFP during which a Proponent will be permitted to rectify its Proposal to satisfy the mandatory submission requirements of this RFP.
Resolution Extension Period As defined in Section 2.03(b).
Extension Period has the meaning set forth in Section 2.11.
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Commencement Date of the Contract means the date of signing of the Contract between the Purchaser and the Contractor.
Extension Term means the time period defined in §2.C.
Extended Term shall have the meaning given such term in Section 2.4.
Extended Use Period means the period beginning on the 1st day in the compliance period on which such building is part of a qualified low-income housing project, and ending on the later of the date specified by such agency in such agreement, or the date which is 15 years after the close of the compliance period.
Second Extension Period means a period of twelve (12) consecutive months following the First Extended Maturity Date.