Examples of Guaranteed Dates in a sentence
As used herein, the term “Owner Caused Delay” shall mean a delay that will adversely and materially affect the critical path of the Work or Contractor’s timely completion of its Guaranteed Dates, which delay was caused primarily as a result of Owner’s unexcused delay or failure to perform its obligations hereunder.
Contractor shall promptly notify Owner in writing of any occurrence that Contractor has reason to believe will adversely affect the completion of the Work by the Guaranteed Dates or materially adversely affect completion of the Work in accordance with the Project Schedule.
In the event Contractor desires to claim an Owner Caused Delay, it must submit a request for Changes pursuant to Section 7.02(c), and Contractor shall be entitled to suspension of performance or extension of time (including an extension of any Guaranteed Dates) together with demonstrated reasonable extended Job Site overhead, standby labor or other costs, including but not limited to, idle equipment costs, incurred by reason of such delay pursuant to the terms of this Section and Section 7.02(c).
The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.
The CPM Schedule shall be consistent with the Key Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Guaranteed Dates.
The only Guaranteed Dates for such Units are as designated in Section 4.1(a).
The CPM Schedule shall be consistent with the Project Schedule, including the Milestone Schedule Dates and the Guaranteed Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Milestone Schedule Dates and the Guaranteed Dates.
Owner's review of the CPM Schedule shall not relieve Contractor of any obligations for the performance of the Work, change the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Dates, or the Final Completion Guaranteed Dates.
Notwithstanding anything to the contrary in the foregoing, Contractor shall remain solely responsible for performing the Work in accordance with this Agreement, including Contractor’s obligation to achieve Substantial Completion of each Unit by the applicable Substantial Completion Guaranteed Dates.
Failure by Owner to pay any amount reasonably in dispute that is identified in accordance with Section 6.5 until resolution of such dispute in accordance with this Agreement shall not alleviate, diminish, modify nor excuse the performance of, Contractor’s obligations to perform hereunder in any respect, including Contractor’s obligation to meet the Project Guaranteed Dates.