IP Completion Time definition

IP Completion Time means 11pm (London time) on 31 December 2020.
Sample 1Sample 2Sample 3

Examples of IP Completion Time in a sentence

  • From IP Completion Time the UK ceased to be part of the European Economic Area and left the EU customs union and single market.

  • The UK and EU/European Atomic Energy Community signed the 'Trade and Cooperation Agreement' on 30 December 2020 (the "Trade and Cooperation Agreement") in order to govern the future relationship between the UK and the EU following IP Completion Time.

  • The Withdrawal Agreement (the European Union (Withdrawal) Act 2018, as amended by the European Union (Withdrawal Agreement) Act 2020 (as so amended, the "EUWA") together with secondary legislation enacted under powers provided in the EUWA ensures that the UK has a functioning statute book from IP Completion Time.

  • On 31 December 2020 at 11pm ("IP Completion Time") the transition period agreed under the 'Agreement on the withdrawal of the United Kingdom of Great Britain and Northern Ireland from the European Union and the European Atomic Energy Community' (the "Withdrawal Agreement") ended.

Related to IP Completion Time

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Execution Time means the date and time that this Agreement is executed and delivered by the parties hereto.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.