Phase Completion definition

Phase Completion means the completion of all activities for each Phase as set forth in Sections 6.2 and 6.4 of this Agreement.
Sample 1Sample 2Sample 3
Phase Completion has the meaning given to it in Section 4.2.2;
Sample 1
Phase Completion means the Substantial Completion of Improvements to the applicable Phase as identified on Exhibit B and such Phase being included on the tax rolls as a result of the Substantial Completion of the Improvements included in such Phase.
Sample 1

Examples of Phase Completion in a sentence

  • Phase Completion is defined as the CONSULTANT having fully completed all required tasks and receiving written approval from COUNTY of all of the required document(s) or activities.

  • Multiple re-submittals may be required before Phase Completion is granted.

  • Without prejudice to Clauses 40 (DBFM Co Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • The following chart presents the projected data for each phase of the Project: Phase # of Homes Effective Date Phase Completion Date Minimum Phase Valuation Phase Approx.

  • The Operator shall comply with applicable laws, rules, and regulations concerning the source(s) of water used in the Drilling Phase, Completion Phase, and Production Phase.

  • Notwithstanding that the Works [relating to a Phase] may have been completed in accordance with this Agreement, the Actual Completion Date [Phase Actual Completion Date] may only occur on a date on or after the Completion Date [Phase Completion Date] unless the Authority, in its absolute discretion, agrees otherwise in writing.

  • Without prejudice to Clauses 40 (Sub-hubco Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • AURA shall provide Contractor with a "Phase Completion – Notice to Proceed" letter upon successful completion.

  • Operator shall provide written notice to the City no less than thirty (30) days prior to the commencement of any of the following: Construction Phase (unless the Construction Phase commences within forty-five (45) days of the approval of the applicable Form 2 or Form 2A), Drilling Phase, Completion Phase, or any recompletion, re-drilling, or plugging and abandonment of a Well.

  • The NCSC team saw promise, however, in a CASA program for Connecticut’s children.


More Definitions of Phase Completion

Phase Completion for each Phase of the Development shall mean the first day of the month following the expiration of the 90th day after the sale or transfer of the portion of the final Residential Units of the Phase which results in the Phase being Substantially Complete, provided however Phase Completion for any phase shall not include sale or transfer of the Affordable Housing.
Sample 1
Phase Completion means the date that is (this information is contained in the exempt part of the report) Working Days after the earliest of:
Sample 1

Related to Phase Completion

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Phase 2 means the phase of the ATP comprised of: (1) improvements to the State Street Substation to receive Rebuilt Line 972; (2) the rebuilding of NYSEG’s existing Line 972 not performed in Phase 1; (3) construction of Relocated Line 15; (4) the construction of Bused Line 5; (5) improvements to the Elbridge Substation to receive Relocated Line 15; and (6) improvements to the Elbridge Substation to receive Bused Line 5.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract.

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Phase III means human clinical trials, the principal purpose of which is to establish substantial evidence of both safety and efficacy in patients with the disease or condition being studied, as more fully defined in 21 C.F.R. §312.21(c) or similar clinical study in a country other than the United States. Phase III shall also include any other human clinical trial intended to serve as a pivotal trial to support the submission of an application for regulatory approval.

  • Phase I means the first part of the tuition incentive assistance program defined as the academic period of 80 semester or 120 term credits, or less, leading to an associate degree or certificate.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Phase 3 means the period commencing on the day after the Phase 2 implementation date and ending on the Phase 3 implementation date (as defined below).

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Phase II means the second part of the tuition incentive assistance program which provides assistance in the third and fourth year of 4-year degree programs.

  • Feasibility Study means the evaluation and analysis of the potential of a project, which aims at supporting the process of decision-making by objectively and rationally uncovering its strengths and weaknesses, opportunities and threats, as well as identifying the resources required to carry it through and ultimately its prospects for success;

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Phase 1 Study means a clinical study of a drug candidate in human patients with the primary objective of characterizing its safety, tolerability, and pharmacokinetics and identifying a recommended dose and regimen for future studies as described in 21 C.F.R. §312.21(a), or a comparable clinical study prescribed by the relevant Regulatory Authority in a country other than the United States. The drug candidate can be administered to patients as a single agent or in combination with other investigational or marketed agents.

  • Stage 1 means the area at Port Xxxxxxx which is the subject of this Agreement and of the ERMP and which is shown bordered in purple as “stage 1” on Department of Land Administration 4 Miscellaneous Plan No. 1743;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity