Target Completion Date has the meaning given such term in Section 3.3(b).
Project Completion Date means the date on which the Completion Certificate is issued;
Final Completion Date means the date on which Final Completion occurs.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Substantial Completion Date means the date on which Substantial Completion occurs.
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.
Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).
Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);
Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;
Billing Commencement Date means the earlier of:
Construction Completion means physical construction of a cleanup action component is complete.
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;
Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date
Commissioning Period has the meaning set forth in Attachment T.
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.