Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).
bicycle parking space – occupant means an area that is equipped with a bicycle rack or locker for the purpose of parking and securing bicycles, and:
Leased space means individual storage space at a self-service storage facility which is rented to an occupant pursuant to a rental agreement.
Qualified Tenants means any tenants who have incomes of 60% or less of the area median gross income, as adjusted for family size, so as to make the Project eligible for LIHTC.
Open space means undeveloped land, a naturally landscaped area, or a formal or man-made landscaped area that provides a connective link or a buffer between other resources.
Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.
Qualified Tenant means a tenant (i) with income not exceeding that permitted by the Minimum Set-Aside Test who leases a Low-Income Apartment Unit in the Project under a lease having an original term of not less than 6 months at a rent which satisfies the Rent Restriction Test and (ii) complying with any other requirements imposed by the Project Documents.
Collocation Space means an area of space located in a Building to be used by CLEC to house telecommunications equipment. Additionally, roof or wall space used for wireless interconnection shall be included in the definition where applicable.
Usable space means all the space on a pole, except the portion below ground level, the 20 feet of safety clearance space above ground level, and the safety clearance space between communications and power circuits. There is a rebuttable presumption that six feet of a pole are buried below ground level.
Landlord’s Work means the work of constructing the Tenant Improvements.
Protected Space Operations means all Launch or Transfer Vehicle activities, ISS activities, and Payload activities on Earth, in outer space, or in transit between Earth and outer space in implementation of the IGA, MOUs concluded pursuant to the IGA, implementing arrangements, and contracts to perform work in support of NASA's obligations under these Agreements. It includes, but is not limited to:
domestic premises means any premises used wholly or partly as a dwelling or intended for such use;
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.
Open space land means (a) any land area so designated by an
bicycle parking space – visitor means an area that is equipped with a bicycle rack for the purpose of parking and securing bicycles, and:
Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;
Available Space means the balance of the rentable square footage in the Building not already included as part of the Premises, which is not occupied by a tenant or which is occupied by an existing tenant whose lease is expiring within 6 months or less and such tenant does not wish to renew (whether or not such tenant has a right to renew) its occupancy of such space. If there is any Available Space in the Building, Landlord shall, at such time as Landlord shall elect so long as Tenant’s rights hereunder are preserved, deliver to Tenant written notice (the “Expansion Notice”) of such Available Space, together with the terms and conditions on which Landlord is prepared to lease Tenant such Available Space; provided that Base Rent shall be at the Market Rate (as defined in Section 40(a) below) for such Available Space. Tenant shall be entitled to exercise its right under this Section 39(a) only with respect to the entire Available Space described in such Expansion Notice (“Identified Available Space”). Tenant shall have 5 business days following delivery of the Expansion Notice to deliver to Landlord written notification of Tenant’s exercise of the Expansion Right with respect to the Identified Available Space (“Exercise Notice”). Tenant shall be entitled to lease such Identified Available Space upon the terms and conditions set forth in the Expansion Notice. If Landlord and Tenant are unable to agree on the Market Rate for the Available Space after negotiating in good faith within 5 days after Tenant’s delivery of an Exercise Notice, the applicable Market Rate will be determined through arbitration in accordance with Section 40(b). Tenant acknowledges and agrees that, if Tenant has delivered an Exercise Notice pursuant to this Section 39(a), Tenant shall have no right thereafter to rescind or elect not to lease the Available Space. Tenant acknowledges that the Term of the Lease with respect to the Identified Available Space may not be co-terminous with the Term of the Lease with respect to the original Premises. Notwithstanding anything to the contrary contained herein, Tenant shall have no right to exercise the Expansion Right and the provisions of this Section 39(a) shall no longer apply after the date that is 9 months prior to the expiration of the Base Term if Tenant has not exercised its Extension Right pursuant to Section 40. If Tenant fails to deliver an Exercise Notice to Landlord for the Identified Available Space within the required 5 business day period, Tenant shall be deemed to have forever waived its rights under this Section 39(a) to lease the Identified Available Space, and Landlord shall have the right to lease the Identified Available Space to any third party on any terms and conditions acceptable to Landlord.
Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.
Licensed Space means the indoor and outdoor space on the premises approved by the department for the purpose of providing licensed child care.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Customer Premises means premises owned, controlled or occupied by the Customer which are made available for use by the Supplier or its Sub-Contractors for provision of the Services (or any of them);
Space Lease The space or occupancy lease pursuant to which any Borrower holds a leasehold interest in the related Mortgaged Property, together with any estoppels or other agreements executed and delivered by the lessor in favor of the lender under the related Mortgage Loan(s).
Habitable space means space in a building used for living, sleeping, eating, or cooking. Habitable space does not include a heater or utility room, a crawl space, a basement, an attic, a garage, an open porch, a balcony, a terrace, a court, a deck, a bathroom, a toilet room, a closet, a hallway, a storage space, and other similar spaces not used for living, sleeping, eating, or cooking.
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.