Stage 4 EPC Agreement definition

Stage 4 EPC Agreement means the engineering, procurement and construction agreement being contemplated by (or if executed, then between) Owner and Contractor for the engineering, procurement, construction, commissioning, start-up and testing of the Stage 4 Liquefaction Facility, to be located at the Stage 4 Site.
Sample 1Sample 2Sample 3

Examples of Stage 4 EPC Agreement in a sentence

  • Without limiting the foregoing, if there are common issues of fact or law in connection with any Disputes in an arbitration conducted under this Article and any disputes in connection with any arbitration under the Stage 1 EPC Agreement, the Stage 2 EPC Agreement or the Stage 4 EPC Agreement, either Party may consolidate the arbitrations to the extent necessary to avoid inconsistent determinations.

  • Owner shall provide Contractor with reasonable prior notice of access to the Off-Site Rights of Way and Easements by (i) any of Owner’s other contractors or subcontractors seeking to perform work within such Off-Site Rights of Way and Easements (except with respect to Contractor’s work performed under the Stage 1 EPC Agreement, the Stage 2 EPC Agreement or the Stage 4 EPC Agreement), and (ii) any Landowner.

  • For the avoidance of doubt, this Section 8.2 shall apply to any loss or damage to the Work caused by, arising out of or resulting from, any activities, events or omissions occurring in connection with the Stage 1 EPC Agreement, Stage 2 EPC Agreement or Stage 4 EPC Agreement.

  • Owner shall provide Contractor with reasonable notice of any request for access to the Stage 3 Site by (i) any of Owner’s other contractors or subcontractors seeking to perform work at the Stage 3 Site (except with respect to Contractor’s work performed under the Stage 1 EPC Agreement, the Stage 2 EPC Agreement or the Stage 4 EPC Agreement) or (ii) any Landowner.

  • Without limiting the foregoing, the waivers and disclaimers of liability, releases from liability, exclusions, limitations and apportionments of liability and indemnities expressed in the Stage 1 EPC Agreement, the Stage 2 EPC Agreement, the Stage 4 EPC Agreement and this Agreement shall apply to the work performed under each agreement respectively and shall not supersede any such rights, obligations or liabilities that arise out of the other agreement.

  • Notwithstanding anything to the contrary in this Agreement, the work performed under the Stage 1 EPC Agreement is governed by the Stage 1 EPC Agreement, the work performed under the Stage 2 EPC Agreement is governed by the Stage 2 EPC Agreement, the work performed under the Stage 4 EPC Agreement is governed by the Stage 4 EPC Agreement and the Work performed under this Agreement is governed by this Agreement.

  • Owner shall provide Contractor with reasonable prior notice of access to the Off- Site Rights of Way and Easements by (i) any of Owner’s other contractors or subcontractors seeking to perform work within such Off-Site Rights of Way and Easements (except with respect to Contractor’s work performed under the Stage 1 EPC Agreement, the Stage 2 EPC Agreement or the Stage 4 EPC Agreement), and (ii) any Landowner.

Related to Stage 4 EPC Agreement

  • EPC Agreement means the agreement between UAMPS and the EPC Contractor with respect to the engineering, procurement and construction of the Initial Facilities.

  • Stage 1 means the area at Port Xxxxxxx which is the subject of this Agreement and of the ERMP and which is shown bordered in purple as “stage 1” on Department of Land Administration 4 Miscellaneous Plan No. 1743;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Development Agreement has the meaning set forth in the Recitals.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • O&M Agreement means the agreement(s), if any, between the Company and the O&M Contractor for the operation and maintenance of the Facility to be entered into between the Company and the O&M Contractor, as amended or superseded from time to time;

  • MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;

  • Clinical Supply Agreement has the meaning set forth in Section 4.2.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Phase 2 Clinical Trial means a human clinical trial of a product in any country that would satisfy the requirements of 21 C.F.R. 312.21(b) and is intended to explore a variety of doses, dose response, and duration of effect, and to generate initial evidence of clinical safety and activity in a target patient population, or a similar clinical study prescribed by the relevant Regulatory Authorities in a country other than the United States.

  • CMPPA Agreement means the CMPPA Agreement between the SSA and CHHS.

  • Interconnection Feasibility Study means either a Generation Interconnection Feasibility Study or Transmission Interconnection Feasibility Study.

  • service delivery and budget implementation plan means a detailed plan approved by the executive mayor of the municipality, in terms of section 53(l) (c) (ii) of the MFMA, for implementing the municipality's delivery of municipal services and which indicate –

  • Commercial Supply Agreement has the meaning set forth in Section 5.2.

  • Additional SDU Study means a deliverability study that a Developer may elect to pursue as that term is defined in OATT Section 25 (OATT Attachment S). For purposes of Section 23.4.5 of this Attachment H, “Affiliated Entity” shall mean, with respect to a person or Entity:

  • Generation Interconnection Feasibility Study means a study conducted by the Transmission Provider (in coordination with the affected Transmission Owner(s)) in accordance with Tariff, Part IV, section 36.

  • Project Scope means the description or activity of work to be accomplished on the Project.

  • Development Phase means the period before a vehicle type is type approved.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • SCM Agreement means the Agreement on Subsidies and Countervailing Measures in Annex 1A to the WTO Agreement;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Phase 1 Clinical Trial means a human clinical trial of a Licensed Product that would satisfy the requirements of 21 C.F.R. 312.21(a) or corresponding foreign regulations.

  • Development Agreements means all development, utility or similar agreements included in the Permitted Encumbrances.

  • Development Milestone Event has the meaning set forth in Section 7.2.1.

  • Collaborative pharmacy practice agreement means a written and signed