4Documenting Weather Delay Days Sample Clauses

4Documenting Weather Delay Days. Upon receipt of the Proceed Order and continuing throughout the Contract, CM/GC shall record actual Weather Delay Days incurred at the Site and describe the weather’s impact to the critical path of Work based on the Overall Project Schedule. Weather Delay Days shall be documented by CM/GC and contemporaneously submitted to Owner’s Contract Compliance Specialist for verification. Not later than ten days after the end of each calendar month, CM/GC shall submit a report to Design Professional documenting the number of Weather Delay Days, verified by the CCS, incurred in the previous month. As a Design Professional’s Decision, Design Professional shall determine if each documented Weather Delay Day impacts the critical path.
Sample 1
AutoNDA by SimpleDocs

Related to 4Documenting Weather Delay Days

  • Construction Preparation Period 2.1.3 Construction Management Plan

  • Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.

  • Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.

  • Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.

  • COMPLETE STATEMENTS 1 THROUGH 5 BELOW 1. This request is for an: Update Amendment See Contract Modification Procedure for an explanation of these terms. 2. The intent of this submittal is to request: Addition of new products or services Deletion of products or services Change in pricing level Other Update Other Amendment

  • STRIKES, LOCKOUTS AND PICKET LINES The Union agrees that during the life of this Agreement, the Union or its bargaining unit members will not authorize, instigate, aid or engage in any work stoppage, slowdown, sickout, refusal to work, picketing or strike against the Employer and/or the Agency, its goods, property or on its property. The Agency agrees that during the life of this Agreement there will be no lockout. Upon notification confirmed in writing by the Employer to the Union that certain bargaining unit members covered by this Agreement are engaging in strike activity in violation of this Article, the Union shall advise such striking employees in writing, with a copy to the Department of Administrative Services, to return to work immediately. Such notification by the Union shall not constitute an admission that it has caused or counseled such strike activity.

  • Non-Business Days If an Interest Period would otherwise end on a day which is not a Business Day, that Interest Period will instead end on the next Business Day in that calendar month (if there is one) or the preceding Business Day (if there is not).

  • Turnaround Time The number of hours between scheduled shifts shall not be less than seven and one-half (7-1/2) hours. Violations shall be compensated at the rate of time and one-half for all hours worked on the shift following the hours of rest.

  • Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.

  • Computation of Period of Days, Deadline In computing a period of days, when the ending date is not 54 specified, the first day is excluded and the last day is included, e.g., three days after MEC. If any deadline falls on a Saturday, 55 Sunday or federal or Colorado state holiday (Holiday), such deadline Will Will Not be extended to the next day that is not

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!