DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage or Destruction If any Property shall be damaged or destroyed, in whole or in part, by fire or other property hazard or casualty, Borrower shall give prompt notice thereof to Lender and one hundred (100%) percent of the net amount of all insurance proceeds received by Lender or Borrower as a result of such damage or destruction after deduction of reasonable costs and the expenses, if any, in collecting the same, shall be applied in reduction of the outstanding Principal Balance under the Note pertaining to the Damaged Property. Notwithstanding anything to the contrary set forth above, if a particular Property (a "DAMAGED PROPERTY") shall be damaged or destroyed, in whole or in part, by fire or other casualty, Lender shall, in accordance with the provisions of this Section hereinafter set forth, make the net amount of all insurance proceeds received by Lender pursuant to the provisions of this Agreement as a result of such damage or destruction after deduction of its reasonable costs and expenses, if any, in collecting the same (hereinafter referred to as the "NET PROCEEDS") available for the repair and restoration of the Damaged Property, provided that (i) no default shall have occurred and shall be continuing under the Loan Documents, (ii) Borrower shall commence the repair and restoration of the Damaged Property, as nearly as possible to the condition the Damaged Property was in immediately prior to such fire or other casualty, with such alterations as may be approved by Lender, as soon as reasonably practicable, and shall diligently pursue the same to satisfactory completion, (iii) Lender shall be satisfied that any operating deficits which will be incurred with respect to the Damaged Property as a result of the occurrence of any such fire or other casualty will be covered out of the Net Proceeds or by Borrower out-of-pocket or with the proceeds, if any, of business interruption or rental interruption insurance, (iv) Lender shall be satisfied that, within a reasonable period of time, not to exceed one hundred eighty (180) days following the completion of such repair and restoration of the Damaged Property, the gross cash flow and the net cash flow of the Damaged Property will be restored to a level sufficient to cover all carrying costs and operating expenses of the Damaged Property, (v) Lender shall be satisfied that the repair and restoration of the Damaged Property will be completed on or before the earlier to occur of (w) ninety (90) days prior to the Maturity Date, or (x) the date on which the business interruption insurance covered by such Borrower shall expire, (vi) Lender shall be satisfied that all of the terms, covenants and provisions of this Agreement and the other Loan Documents will continue to be complied with during and subsequent to the completion of such repair and restoration and (vii) Borrower and ARC IV shall execute and deliver to Lender a completion guaranty in form and substance satisfactory to Lender pursuant to the provisions of which Borrower and ARC IV shall jointly and severally guaranty to Lender the lien-free completion of the repair and restoration of the Damaged Property in accordance with the provisions of this paragraph. The Net Proceeds shall be held by Lender in an interest-bearing account, and until disbursed in accordance with the provisions of this paragraph, shall constitute additional security for the payment of the Debt. The Net Proceeds together with interest earned thereon, shall be disbursed by Lender to, or as directed by, Borrower from time to time during the course of the repair and restoration of the Damaged Property, upon receipt of evidence satisfactory to Lender (which evidence shall in each instance and to the full extent required by Lender include receipted bills, invoices, lien waivers and a continuation and date down of title to the Damaged Property in form satisfactory to Lender and issued by the title company insuring the lien of the Mortgage encumbering such Property or another title company satisfactory to Lender) that (i) all materials installed and work and labor performed (except to the extent that they are to be paid for out of the requested disbursement) in connection with the repair and restoration of the Damaged Property have been paid for in full, and (ii) there exist no notice of pendency, stop order, notice of intention to file mechanic's or materialman's lien, mechanic's or materialman's lien or other lien or encumbrance of any nature whatsoever on the Damaged Property arising out of the repair and restoration of the Damaged Property which have not either been fully bonded to the satisfaction of Lender and discharged of record or in the alternative fully insured over to the satisfaction of Lender by the title company insuring the lien of the Mortgage encumbering the Damaged Property. The repair and restoration of the Damaged Property shall be done and completed by Borrower in an expeditious and diligent fashion and in compliance with all applicable governmental laws, rules and regulations (including, without limitation, all applicable Environmental Requirements), and all plans and specifications required in connection with the repair and restoration of the Damaged Property shall be subject to review and acceptance in all respects by Lender and by the Consultant. If Lender fails to respond within ten (10) Business Days following a request and submissions of plans and specifications for approval, such plans and specification shall be deemed approved by Lender. Upon the occurrence of an Event of Default, Lender shall have the use of such plan and specifications and all permits, licenses and approvals required or obtained in connection with the repair and restoration of the Damaged Property. The identity of the contractors, subcontractors and materialmen engaged in the repair and restoration of the Damaged Property, as well as the contracts under which they have been engaged, shall be identified to Lender and Consultant, if any. All costs and expenses incurred by Lender in connection with making the Net Proceeds available for the repair and restoration of the Damaged Property including, without limitation, reasonable counsel fees and reasonable fees of the Consultant, shall be paid by Borrower. In no event shall Lender be obligated to make disbursements of the Net Proceeds in excess of an amount equal to the costs actually incurred from time to time for work in place as part of the repair and restoration of the Damaged Property,
ABATEMENT OF RENT; LESSEE'S REMEDIES (a) In the event of (i) Premises Partial Damage or (ii) Hazardous Substance Condition for which Lessee is not legally responsible, the Base Rent, Common Area Operating Expenses and other charges, if any, payable by Lessee hereunder for the period during which such damage or condition, its repair, remediation or restoration continues, shall be abated in proportion to the degree to which Lessee's use of the Premises is impaired, but not in excess of proceeds from insurance required to be carried under Paragraph 8.3(b). Except for abatement of Base Rent, Common Area Operating Expenses and other charges, if any, as aforesaid, all other obligations of Lessee hereunder shall be performed by Lessee, and Lessee shall have no claim against Lessor for any damage suffered by reason of any such damage, destruction, repair, remediation or restoration.
(b) If Lessor shall be obligated to repair or restore the Premises under the provisions of this Paragraph 9 and shall not commence, in a substantial and meaningful way, the repair or restoration of the Premises within ninety (90) days after such obligation shall accrue, Lessee may, at any time prior to the commencement of such repair or restoration, give written notice to Lessor and to any Lenders of which Lessee has actual notice of Lessee's election to terminate this Lease on a date not less than sixty (60) days following the giving of such notice. If Lessee gives such notice to Lessor and such Lenders and such repair or restoration is not commenced within thirty (30) days after receipt of such notice, this Lease shall terminate as of the date specified in said notice. If Lessor or a Lender commences the repair or restoration of the Premises within thirty (30) days after the receipt of such notice, this Lease shall continue in full force and effect. "Commence" as used in this Paragraph 9.6 shall mean either the unconditional authorization of the preparation of the required plans, or the beginning of the actual work on the Premises, whichever occurs first.
DAMAGE TO LEASED PREMISES In the event the building housing the Premises shall be destroyed or damaged as a result of any fire or other casualty which is not the result of the intentional acts or neglect of Lessee and which precludes or adversely affects the Lessee’s occupancy of the Premises, then in every such cause, the rent herein set forth shall be abated or adjusted according to the extent to which the leased Premises have been rendered unfit for use and occupation by the Lessee and until the demised Premises have been put in a condition at the expense of the Lessor, at least to the extent of the value and as nearly as possible to the condition of the Premises existing immediately prior to such damage. It is understood, however, in the event of total or substantial destruction to the Premises that in no event shall the Lessor's obligation to restore, replace or rebuild exceed an amount equal to the sum of the insurance proceeds available for reconstruction with respect to said damage.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Landlord Liability Tenant, its successors, and assigns shall not assert nor seek to enforce any claim for breach of this Lease against any of Landlord’s assets other than Landlord’s interest in the Industrial Center. Tenant agrees to look solely to such interest for the satisfaction of any liability or claim against Landlord under this Lease. In no event whatsoever shall Landlord (which term shall include, without limitation, any general or limited partner, trustees, beneficiaries, officers, directors, or stockholders of Landlord) ever be personally liable for any such liability.
