Additional Uncontrollable Circumstance Relief Associated with Permitting Obligations Sample Clauses

Additional Uncontrollable Circumstance Relief Associated with Permitting Obligations. The Company shall be entitled to seek Uncontrollable Circumstance relief in accordance with and to the extent provided in Section 12.9 in the event that (1) the Company is delayed in the performance of the Design/Build Work due to a third party challenge to an “agency action”, as defined in Chapter 120 of Title X of the Florida Statutes, in connection with any Governmental Approval, (2) a Governmental Body fails to comply with Applicable Law in connection with a Governmental Approval application, or (3) the imposition of arbitrary and capricious terms and conditions in connection with a Governmental Approval. Any price relief associated with a Governmental Body delay under this subsection shall be limited to the Company’s reasonable daily general conditions costs, subject to Cost Substantiation by the Company, for the number of days of delay caused by the applicable Governmental Body but only to the extent any such Governmental Body delay actually causes delay in the Company’s critical path completion schedule after the exercise of all commercially reasonable mitigation efforts by the Company.
Sample 1
AutoNDA by SimpleDocs

Related to Additional Uncontrollable Circumstance Relief Associated with Permitting Obligations

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • Uncontrollable Forces Tariff Provisions Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Participating Generator and references to the CAISO Tariff shall be read as references to this Agreement.

  • Action if Other Event of Default If any Event of Default (other than any Event of Default described in clauses (b) through (d) of Section 8.1.5 with respect to the Borrower) shall occur for any reason, whether voluntary or involuntary, and be continuing, the Facility Agent, upon the direction of the Required Lenders, shall by notice to the Borrower declare all of the outstanding principal amount of the Loan and other Obligations to be due and payable and/or the Commitments (if not theretofore terminated) to be terminated, whereupon the full unpaid amount of the Loan and other Obligations shall be and become immediately due and payable, without further notice, demand or presentment, and/or, as the case may be, the Commitments shall terminate.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Individual Special Circumstance Arrangements Notwithstanding Article 2.02, the Home and the Union may agree in certain circumstances, to adjust the schedule of an individual full-time employee who normally works seventy five (75) hours bi-weekly, to enable an average bi-weekly work assignment of sixty (60) to seventy five (75) hours. (a) Such an arrangement shall be established by mutual agreement of the Home and the Union and the employee affected. The parties agree that the arrangement applies to an individual, not to a position. The parties will agree to the scheduling provisions that will apply to the employee including that no additional shifts will be scheduled for employees working Individual Special Circumstances Arrangements. (b) The parties shall determine the introduction of a special circumstance arrangement. Issues related to vacation, paid holidays and benefit coverage will be determined by the Home and the Union. The employee will retain full-time status, including but not limited to seniority and service. (c) Any party may discontinue the special circumstance arrangement with notice as determined within the agreement. In the event that the employee affected resigns, transfers, is laid off or terminated, the arrangement will be deemed to be discontinued immediately, unless the parties mutually agree otherwise. (d) It is understood and agreed that these arrangements are based on individual circumstances and each agreement is made on a without prejudice or precedent basis.

  • Notification of Event of Default Borrower shall notify Agent immediately of the occurrence of any Event of Default.

  • Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover. 30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to: (a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due; (b) 60.5% (sixty point five per cent) of the Adjusted Equity; and 30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.

  • CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!