Advance of Funds for Design Work Sample Clauses

Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement or this Agreement by the NIGC, Lakes shall advance such funds as are reasonably necessary to proceed prior to Bank Closing with site and facility planning, architectural renderings and plans, including payments to the Architect pursuant to the Design Agreement, engineering and environmental services, working drawings and construction contract bidding documents. All amounts so advanced by Lakes prior to NIGC Approval and Bank Closing shall be a part of the development cost of the Enterprise and shall be advanced under the Lakes Note as part of the Lakes Development Loan.
Sample 1Sample 2
AutoNDA by SimpleDocs
Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement by the NIGC, Developer shall advance such funds as Developer and the Construction Committee mutually agree are reasonably necessary to proceed with site and facility planning, architectural renderings and plans, and engineering and environmental services. Fifteen (15) days prior to the first draw of the Financing, Developer shall provide the Construction Committee with a final detailed schedule with totals of all reimbursable project costs up to the date of the first draw. Developer shall be reimbursed from the proceeds of Financing for these costs as a component of the first draw of the Financing. In addition, the Tribe shall be entitled to reimbursement from the proceeds of Financing for such out of pocket costs and expenses as Developer and the Construction Committee mutually agree are reasonably necessary to proceed with site and facility planning for the Project. Reimbursable project costs shall include, but not be limited to, land development costs, engineering and architectural expenses, marketing, legal and consultant costs, project management costs, financing costs and all other pre-construction professional costs. All such costs incurred after the availability of Financing proceeds shall be included in monthly draws against the Financing. The Tribe and Developer agree that such project costs shall not be subject to repayment or reimbursement other than from the proceeds of Financing, and neither party shall have any liability to the other for the repayment of such reimbursable project costs.
Sample 1
Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement or this Agreement by the NIGC, MANAGER shall advance such funds as are reasonably necessary to proceed with site and facility planning, architectural renderings and plans, including payments to the Architect pursuant to the Design Agreement, engineering and environmental services, working drawings and construction contract bidding documents, and the advances shall be repaid to MANAGER from the first draws under the Loan to the extent proceeds of the Loan are available for this purpose. After the Effective Date, the Architect shall be compensated for services rendered in accordance with the Design Agreement out of Loan proceeds, subject to and in accordance with the terms, conditions and provisions of the Loan Agreement.
Sample 1
Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement or this Agreement by the NIGC or the BIA, CEG shall advance as a Reimbursable Project Cost such funds as are necessary to proceed with site and facility planning, architectural renderings and plans, including payments to the Design Team pursuant to the Design Agreement, engineering and environmental services, working drawings and construction contract bidding documents, and the reimbursable project expenses. These expenses shall be repaid to CEG, at CEG's election, at the time the first draw is made on the Loan. After the Effective Date, the Design Team shall be compensated for services rendered in accordance with the Design Agreement out of Loan proceeds, subject to and in accordance with the terms, conditions and provisions of the Loan Agreement.
Sample 1
Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement or this Agreement by the NIGC, KAR shall advance such funds as are reasonably necessary to proceed with site and facility planning, architectural renderings and plans, including payments to the Architect pursuant to the Design Agreement, engineering and environmental services, working drawings and construction contract bidding documents, and the advances shall be repaid to KAR as a Transition Loan or from the first draws under the Loan to the extent proceeds of the Loan are available for this purpose. After the Effective Date, the Architect shall be compensated for services rendered in accordance with the Design Agreement out of Loan proceeds, subject to and in accordance with the terms, conditions and provisions of the Loan Agreement.
Sample 1
Advance of Funds for Design Work. Notwithstanding any lack of approval of the Management Agreement or this Agreement by the NIGC, FHRI shall advance such funds as are reasonably necessary to proceed with site and facility planning, architectural renderings and plans, including payments to the Architect pursuant to the Design Agreement, engineering and environmental services, working drawings and construction contract bidding documents, and the advances shall be repaid to FHRI as a Transition Loan or from the first draws under the Loan to the extent proceeds of the Loan are available for this purpose. After the Effective Date, the Architect shall be compensated for services rendered in accordance with the Design Agreement out of Loan proceeds, subject to and in accordance with the terms, conditions and provisions of the Loan Agreement.
Sample 1

Related to Advance of Funds for Design Work

  • Advance of Funds by Seller After origination, no advance of funds has been made by Seller to the related Mortgagor other than in accordance with the Mortgage Loan documents, and, to Seller’s knowledge, no funds have been received from any person other than the related Mortgagor or an affiliate for, or on account of, payments due on the Mortgage Loan (other than as contemplated by the Mortgage Loan documents, such as, by way of example and not in limitation of the foregoing, amounts paid by the tenant(s) into a lender-controlled lockbox if required or contemplated under the related lease or Mortgage Loan documents). Neither Seller nor any affiliate thereof has any obligation to make any capital contribution to any Mortgagor under a Mortgage Loan, other than contributions made on or prior to the date hereof.

  • ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • Maintenance of Fund's Assets Abroad The Fund, acting through its Board or its duly authorized representative, hereby instructs the Delegate pursuant to the terms of the Custodian Agreement dated as of the date hereof executed by and between the Fund and the Delegate (the Custodian Agreement) to place and maintain the Fund's Assets in countries outside the United States in accordance with Instructions received from the Fund’s Investment Advisor. Such instruction shall constitute an Instruction under the terms of the Custodian Agreement. The Fund acknowledges that (a) the Delegate shall perform services hereunder only with respect to the countries where it accepts delegation as Foreign Custody Manager as indicated on the Delegate’s Global Custody Network Listing; (b) depending on conditions in the particular country, advance notice may be required before the Delegate shall be able to perform its duties hereunder in or with respect to such country (such advance notice to be reasonable in light of the specific facts and circumstances attendant to performance of duties in such country); and (c) nothing in this Delegation Schedule shall require the Delegate to provide delegated or custodial services in any country, and there may from time to time be countries as to which the Delegate determines it will not provide delegation services.

  • CERTIFICATION REGARDING USE OF CONTRACT FUNDS FOR LOBBYING This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20). 1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that: a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. 2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. 3. The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such recipients shall certify and disclose accordingly. This provision is applicable to all Federal-aid projects funded under the Appalachian Regional Development Act of 1965. 1. During the performance of this contract, the contractor undertaking to do work which is, or reasonably may be, done as on-site work, shall give preference to qualified persons who regularly reside in the labor area as designated by the DOL wherein the contract work is situated, or the subregion, or the Appalachian counties of the State wherein the contract work is situated, except: a. To the extent that qualified persons regularly residing in the area are not available. b. For the reasonable needs of the contractor to employ supervisory or specially experienced personnel necessary to assure an efficient execution of the contract work. c. For the obligation of the contractor to offer employment to present or former employees as the result of a lawful collective bargaining contract, provided that the number of nonresident persons employed under this subparagraph (1c) shall not exceed 20 percent of the total number of employees employed by the contractor on the contract work, except as provided in subparagraph (4) below. 2. The contractor shall place a job order with the State Employment Service indicating (a) the classifications of the laborers, mechanics and other employees required to perform the contract work, (b) the number of employees required in each classification, (c) the date on which the participant estimates such employees will be required, and (d) any other pertinent information required by the State Employment Service to complete the job order form. The job order may be placed with the State Employment Service in writing or by telephone. If during the course of the contract work, the information submitted by the contractor in the original job order is substantially modified, the participant shall promptly notify the State Employment Service. 3. The contractor shall give full consideration to all qualified job applicants referred to him by the State Employment Service. The contractor is not required to grant employment to any job applicants who, in his opinion, are not qualified to perform the classification of work required. 4. If, within one week following the placing of a job order by the contractor with the State Employment Service, the State Employment Service is unable to refer any qualified job applicants to the contractor, or less than the number requested, the State Employment Service will forward a certificate to the contractor indicating the unavailability of applicants. Such certificate shall be made a part of the contractor's permanent project records. Upon receipt of this certificate, the contractor may employ persons who do not normally reside in the labor area to fill positions covered by the certificate, notwithstanding the provisions of subparagraph (1c) above. 5. The provisions of 23 CFR 633.207(e) allow the contracting agency to provide a contractual preference for the use of mineral resource materials native to the Appalachian region. 6. The contractor shall include the provisions of Sections 1 through 4 of this Attachment A in every subcontract for work which is, or reasonably may be, done as on-site work.

  • Acceptance of the Work 19.1 No act of, or failure to act by, the Owner or the OWNER'S REPRESENTATIVE during the course of the Work, nor any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the Final Payment by the Owner to Contractor. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof. 19.2 Contractor agrees to guarantee all work under this Contract for a period of one year from the date of Final Payment by the Owner or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required under terms of Owner’s conditional acceptance of elements of the Work the Owner deems marginally substandard. If any unsatisfactory condition or damage develops within the time of this guarantee period due to materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the OWNER’S REPRESENTATIVE, then the Contractor shall, when notified by the Owner or OWNER’S REPRESENTATIVE, immediately place such guaranteed Work in a condition satisfactory to the Owner or OWNER’S REPRESENTATIVE. Such guarantee shall be in addition to any implied warranty under law or other manufacturer’s or product supplier’s warranty. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.

  • ADDITION, DELETION OR MODIFICATION OF FUNDS The Parties hereto may agree, from time to time, to add other Funds to provide additional funding media for the Contracts, or to delete, combine, or modify existing Funds, by amending Schedule A hereto. Upon such amendment to Schedule A, any applicable reference to a Fund, AVIF, or its Shares herein shall include a reference to any such additional Fund. Schedule A, as amended from time to time, is incorporated herein by reference and is a part hereof.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Project Delivery Order Procedures Status of TIPS Members as Related to This Agreement

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!