ALTERATION OF DELIVERY OF THE VESSEL Sample Clauses

ALTERATION OF DELIVERY OF THE VESSEL. In the event of the arbitration of any dispute or difference arising or occurring prior to delivery to, or acceptance by the BUYER of the VESSEL, the award by the arbitrator shall include a finding as to whether or not the DELIVERY DATE of the VESSEL should, as a result of such dispute, be in any way altered thereby.
Sample 1Sample 2Sample 3See All (30)
AutoNDA by SimpleDocs
ALTERATION OF DELIVERY OF THE VESSEL. In the event of reference to arbitration of any dispute or disputes arising out of matters occurring prior to delivery of the Vessel, the award by the arbitration tribunal shall include a declaration as to any postponement of the Delivery Date which the arbitration tribunal may in his/their absolute discretion deem appropriate.
Sample 1Sample 2Sample 3See All (7)
ALTERATION OF DELIVERY OF THE VESSEL. In the event of the arbitration of any dispute or difference arising or occurring prior to delivery to, or acceptance by the BUYER of, the VESSEL, the award by the Arbitration Board shall include a finding as to whether or not the contractual delivery date of the VESSEL should, as a result of such dispute, be in any way altered thereby and/or whether a delay shall be classified as permissible or non-permissible for the purposes of Articles III and/or VIII hereof.
Sample 1Sample 2
ALTERATION OF DELIVERY OF THE VESSEL. Notwithstanding the reference of a dispute for resolution under this Article XIV, the parties shall continue diligently to observe and perform their respective obligations and duties under this CONTRACT as if no dispute had arisen, except if a party has given notice to terminate this CONTRACT. In the event of the arbitration of any dispute or difference arising or occurring prior to delivery to, or acceptance by the BUYER of the VESSEL, the award by the arbitrator shall include a finding as to whether or not the DELIVERY DATE of the VESSEL should, as a result of such dispute, be in any way altered thereby. The effectiveness of Paragraphs 2, 3, 4 and 5 of this Article XIV shall survive delivery of the VESSEL and any termination of this CONTRACT
Sample 1
ALTERATION OF DELIVERY OF THE VESSEL. In the event of reference to the CLASSIFICATION SOCIETY under paragraph 1(b) or (c) above or to arbitration of any dispute or disputes arising or occurring prior to delivery of the VESSEL, the award deciding the said dispute or disputes shall include a declaration as to any postponement of the DELIVERY DATE, which shall be at the absolute discretion of the body deciding the said dispute or disputes
Sample 1

Related to ALTERATION OF DELIVERY OF THE VESSEL

  • Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.

  • Delivery of the Property The Fund will deliver or arrange for delivery to PFPC Trust, all the Property owned by the Portfolios, including cash received as a result of the distribution of Shares, during the term of this Agreement. PFPC Trust will not be responsible for such property until actual receipt.

  • Delivery of Documents; Delivery Dates (a) The Trustee is hereby directed (i) to execute and deliver the Intercreditor Agreement, the Escrow Agreement and the NPA on or prior to the Issuance Date, each in the form delivered to the Trustee by the Company, and (ii) subject to the respective terms thereof, to perform its obligations thereunder. Upon request of the Company and the satisfaction or waiver of the closing conditions specified in the Underwriting Agreement, the Trustee shall execute, deliver, authenticate, issue and sell Applicable Certificates in authorized denominations equaling in the aggregate the amount set forth, with respect to the Applicable Trust, in Schedule I to the Underwriting Agreement evidencing the entire ownership interest in the Applicable Trust, which amount equals the maximum aggregate principal amount of Equipment Notes which may be purchased by the Trustee pursuant to the NPA. Except as provided in Sections 3.03, 3.04, 3.05 and 3.06 of the Basic Agreement, the Trustee shall not execute, authenticate or deliver Applicable Certificates in excess of the aggregate amount specified in this paragraph. The provisions of this Section 5.01(a) supersede and replace the first sentence of Section 3.02(a) of the Basic Agreement, with respect to the Applicable Trust. (b) After the Issuance Date, the Company may deliver from time to time to the Trustee a Closing Notice relating to one or more Equipment Notes. After receipt of a Closing Notice and in any case no later than one Business Day prior to a Scheduled Closing Date as to which such Closing Notice relates (the “Applicable Closing Date”), the Trustee shall (as and when specified in the Closing Notice) instruct the Escrow Agent to provide a Notice of Purchase Withdrawal to the Depositary requesting (A) the withdrawal of one or more Deposits on the Applicable Closing Date in accordance with and to the extent permitted by the terms of the Escrow Agreement and the Deposit Agreement and (B) the payment of all, or a portion, of such Deposit or Deposits in an amount equal in the aggregate to the purchase price of such Equipment Notes to or on behalf of the Company, all as shall be described in the Closing Notice. The Trustee shall (as and when specified in such Closing Notice), subject to the conditions set forth in Section 2 of the NPA, enter into and perform its obligations under the Participation Agreement specified in such Closing Notice (the “Applicable Participation Agreement”) and cause such certificates, documents and legal opinions relating to the Trustee to be duly delivered as required by the Applicable Participation Agreement. If at any time prior to the Applicable Closing Date, the Trustee receives a notice of postponement pursuant to Section 1(e) or 1(f) of the NPA, then the Trustee shall give the Depositary (with a copy to the Escrow Agent) a notice of cancellation of such Notice of Purchase Withdrawal relating to such Deposit or Deposits on such Applicable Closing Date. Upon satisfaction of the conditions specified in the NPA and the Applicable Participation Agreement, the Trustee shall purchase the applicable Equipment Notes with the proceeds of the withdrawals of one or more Deposits made on the Applicable Closing Date in accordance with the terms of the Deposit Agreement and the Escrow Agreement. The purchase price of such Equipment Notes shall equal the principal amount of such Equipment Notes. Amounts withdrawn from such Deposit or Deposits in excess of the purchase price of the Equipment Notes or to the extent not applied on the Applicable Closing Date to the purchase price of the Equipment Notes, shall be re-deposited by the Trustee with the Depositary on the Applicable Closing Date in accordance with the terms of the Deposit Agreement. The provisions of this Section 5.01(b) supersede and replace the provisions of Section 2.02 of the Basic Agreement with respect to the Applicable Trust, and all provisions of the Basic Agreement relating to Postponed Notes and Section 2.02 of the Basic Agreement shall not apply to the Applicable Trust. (c) The Trustee acknowledges its acceptance of all right, title and interest in and to the Trust Property to be acquired pursuant to Section 5.01(b) of this Trust Supplement, the NPA and each Applicable Participation Agreement, and declares that it holds and will hold such right, title and interest for the benefit of all present and future Applicable Certificateholders, upon the trusts set forth in the Agreement. By its acceptance of an Applicable Certificate, each initial Applicable Certificateholder, as a grantor of the Applicable Trust, joins with the Trustee in the creation of the Applicable Trust. The provisions of this Section 5.01(c) supersede and replace the provisions of Section 2.03 of the Basic Agreement, with respect to the Applicable Trust.

  • DATE OF DELIVERY OF PUT NOTICE A Put Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by Investor if such notice is received on or prior to 12:00 noon New York time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon New York time on a Trading Day or at anytime on a day which is not a Trading Day.

  • Delivery of Equipment (a) We will try to deliver Equipment to you on the delivery date (Delivery Date) and at the address (Site) indicated on your Application during normal business hours in that area. (b) Variations at your request to Delivery Date or Site: (i) are at our discretion; and (ii) may be subject to conditions, including extra Charges.

  • Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.

  • Expenses of Delivery of Warrants The Company shall pay all expenses (other than transfer taxes) and other charges payable in connection with the preparation, issuance and delivery of Warrants and Warrant Shares hereunder.

  • Delivery of the Offered Shares The Company shall deliver, or cause to be delivered to the Representative for the accounts of the several Underwriters certificates for the Firm Shares at the First Closing Date, against the irrevocable release of a wire transfer of immediately available funds for the amount of the purchase price therefor. The Company shall also deliver, or cause to be delivered through the facilities of DTC unless the Representative shall otherwise instruct, to the Representative for the accounts of the several Underwriters, certificates for the Option Shares the Underwriters have agreed to purchase at the First Closing Date or the applicable Option Closing Date, as the case may be, against the release of a wire transfer of immediately available funds for the amount of the purchase price therefor. If the Representative so elects, delivery of the Offered Shares may be made by credit to the accounts designated by the Representative through The Depository Trust Company’s full fast transfer or DWAC programs. The certificates for the Offered Shares shall be registered in such names and denominations as the Representative shall have requested at least two full Business Days prior to the First Closing Date (or the applicable Option Closing Date, as the case may be) and shall be made available for inspection on the Business Day preceding the First Closing Date (or the applicable Option Closing Date, as the case may be) at a location in New York City as the Representative may designate. Time shall be of the essence, and delivery at the time and place specified in this Agreement is a further condition to the obligations of the Underwriters.

  • Delivery and Installation Delivery and Installation of the Product will take place at a mutually agreed time between Xxxxxx Xxx Ltd and the Restaurant and will only be carried out after payment in full of the refundable deposit has been made by the Restaurant.

  • Subsequent Delivery of Comfort Letters Each time that the Registration Statement or the Prospectus shall be amended or supplemented to include additional financial information or there is filed with the Commission any document incorporated by reference into the Prospectus which contains additional financial statement information relating to the Company or the Company sells Notes pursuant to a Terms Agreement, the terms of which so require, the Company shall use its best efforts to cause the Company's independent public accountants promptly following such amendment, supplement or filing or on the Settlement Date with respect to such Terms Agreement, as the case may be, to furnish the Agents or to the Agent party to the Terms Agreement, as the case may be, a letter, dated the date of filing of such amendment, supplement or document with the Commission, or such Settlement Date, as the case may be, in form satisfactory to counsel for the Agents (or such Agent), of the same tenor as the portions of the letter referred to in clauses (i) and (ii) of Section 5(e) hereof but modified, as necessary, to relate to the Registration Statement and Prospectus, as amended and supplemented to the date of such letter, and of the same general tenor as the portions of the letter referred to in clause (iii) (other than the information required by clause (B) thereof, except in the case of a Terms Agreement, the terms of which so require) and clause (iv) of said Section 5(e) with such changes as may be necessary to reflect changes in the financial statements and other information derived from the accounting records of the Company; PROVIDED, HOWEVER, that if the Registration Statement or the Prospectus is amended or supplemented primarily to include financial information as of and for a fiscal quarter, the Company's independent certified public accountants may limit the scope of such letter to the unaudited financial statements included in such amendment or supplement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!