We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.
For more information visit our privacy policy.Plumbing fixtures and appliances shall be used only for the purposes for which designed, and no sweepings, rubbish, rags or other unsuitable material shall be thrown or deposited therein. Damage resulting to any such fixtures or appliances from misuse by a tenant or its agents, employees or invitees, shall be paid by such tenant.
HVAC Heating, ventilating and air conditioning.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Contract Database Metadata Elements Title: Xxxxxxx-Xxx Xxxxx Central School District and Xxxxxxx-Xxx Xxxxx Teachers Association (2007)
Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements: (a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work. (b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay. (c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord. (d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Electrical Provide drawings for the following systems: .1 Lighting including circuiting and luminaire identification and switching. Also provide illuminance computer printout for all indoor typical indoor spaces and parking lots. .2 Convenience outlets and circuiting, special outlets and circuiting, television outlets, and power systems and equipment. Provide riser diagrams for all electrical systems including master clock, intercom, fire alarm, ITV, computer networking/telephone. Also, provide for emergency and normal power distribution. Provide luminaire schedule. .3 Panel schedule may be in preliminary form but circuitry must be included. .4 Applicable installation details. .5 General legend and list of abbreviations. .6 Voltage drop computation for all main feeders. .7 Short circuit analysis .8 Provide 1/2" scale floor plan and wall elevations for all electrical rooms.
SPRINKLER SYSTEM If there now is or shall be installed in the Building a "sprinkler system", and such system or any of its appliances shall be damaged or injured or not in proper working order by reason of any act or omission of Tenant, Tenant's agents, servants, employees, licensees or visitors, Tenant shall forthwith restore the same to good working condition at its own expense; and if the New York Board of Fire Underwriters or the New York Fire Insurance Rating Organization or any bureau, department or official of the state or city government, shall require or recommend that any changes, modifications, alterations or additional sprinkler heads or other equipment be made or supplied by reason of Tenant's business, or the location of the partitions, trade fixtures, or other contents of the Premises, Tenant shall, at Tenant's expense, promptly make and supply such changes, modifications, alterations, additional sprinkler heads or other equipment.
Shift Work (1) Except as varied by this Clause, all other aspects of Section 4 of the Agreement shall apply to the working of shift work. (2) The Company has the right to direct Employees to work shift work as required and the Employees shall work the shift work as directed. Shift work will be worked and paid for in accordance with this subclause. (3) Shift work is deemed to be any arrangement of Project Working Hours where the majority of the Ordinary Hours are worked outside of the spread of Ordinary Hours defined at clause 16 - Hours of Work of this Agreement and when Employees are working as such. (4) Ordinary Hours for shift Employees will comprise thirty-six (36) hours per week averaged over a defined work cycle and will not commence before 5.00pm on Sunday night. Such Ordinary Hours are the specified hours under each shift Employee's terms of employment by reference to which annual leave and personal/carer's leave accrue. (5) Prior to the commencement of shift work, the Company shall seek the agreement of the Employees involved. Failing agreement, the Company will provide to the Employees concerned one (1) week's notice of the commencement of shift work and the starting and finishing times of Ordinary Hours of the shifts. (6) Where less than five (5) consecutive shifts are worked then Employees shall be paid at overtime rates in lieu of the shift loading prescribed at subclause (7) of this clause. The consecutive nature of shifts will not be deemed to be broken if work is not carried out on a Saturday, Sunday, RDO or on any public holiday. (7) A shift Employee shall receive a flat loading of twenty-five (25) percent of their Ordinary Hourly Rate for each hour worked. (8) Employees working night shift shall be entitled to stop work for a half-hour without deduction of pay for the purpose of taking a meal break. (9) The Company may stagger the times for Employees to take meal breaks to meet operational requirements. (10) The Company shall structure the Project Working Hours for Employees working night shift to include one (1) half-hour rest break to be taken without deduction of pay by Employees working the Project Working Hours on any night shift.