Application Scheduling
Application Scheduling Sample Clauses
Related to Application Scheduling
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
Vacation Scheduling (a) With the exception of authorized vacation carryover under Clause 18.6, the scheduling and completion of vacations shall be on a calendar-year basis.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Shift Scheduling The parties agree that the following shift schedules are examples of the type which will provide the flexibility required to meet the needs expressed above provided the provisions of Article VII Section 4 (b) (i) and (ii) have been met.
ARBITRATION - SCHEDULING Timely complaints shall be submitted to and determined by an arbitrator. Each arbitration proceeding shall commence not earlier than ten (10) calendar days and not later than thirty (30) calendar days following the date of filing of the complaint.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
PTO Scheduling a. By November 15 of each year, the Company will post on appropriate bulletin boards a schedule showing the PTO days, which are available to each employee for the upcoming year.
Payment Scheduling The earliest possible Scheduled Payment Date for each Xxxxxx will be designated within the portion of the Site through which the Service is offered when you are scheduling the payment. Therefore, the Service will not permit you to select a Scheduled Payment Date less than the earliest possible Scheduled Payment Date designated for each Xxxxxx. When scheduling payments you must select a Scheduled Payment Date that is no later than the actual Due Date reflected on your Xxxxxx statement unless the Due Date falls on a non-Business Day. If the actual Due Date falls on a non-Business Day, you must select a Scheduled Payment Date that is at least one (1) Business Day before the actual Due Date. Scheduled Payment Dates must be prior to any late date or grace period. Depending on the method of payment, your Eligible Transaction Account may be debited prior to the Scheduled Payment Date. For example, if the selected method of payment is a draft, the draft arrives earlier than the Scheduled Payment Date due to expedited delivery by the postal service, and the Xxxxxx immediately deposits the draft, your Eligible Transaction Account may be debited earlier than the Scheduled Payment Date.
Scheduling Checkout Protocols 35.13.1.1 Both Parties shall require all transaction schedules to be tagged in accord with the NERC tagging standard. For reserve sharing and other emergency schedules that are not tagged, the Parties will enter manual schedules after the fact into their respective scheduling systems.
Self Scheduling The Home and the Union may agree to implement a self-scheduling process. Self-scheduling is the mechanism by which employees in a Home create their own work schedules. The purpose of self scheduling is to improve job satisfaction and quality of work life for the participating employees. Self scheduling requires a collaboration of employees and management to ensure proper coverage of the Home and to meet the provisions of the Collective Agreement. It is agreed that self scheduling will be negotiated locally by the Home and the Union and will include a trial period. Each Home must have the majority agreement of the full-time and part-time employees who vote on the issue to agree on a trial period of up to six months. Once the trial period is complete, each Home must have a minimum of 66⅔% agreement of the full-time and part-time employees who vote on the issue to continue with the new schedule on a permanent basis.
