Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default.
(ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.
Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified.
(ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement.
(iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required.
47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender.
47.3 Performance security shall not be required for a contract, if so specified in the TDS.
Covenants of Performance Measurement No interference. Registry Operator shall not interfere with measurement Probes, including any form of preferential treatment of the requests for the monitored services. Registry Operator shall respond to the measurement tests described in this Specification as it would to any other request from an Internet user (for DNS and RDDS) or registrar (for EPP). ICANN testing registrar. Registry Operator agrees that ICANN will have a testing registrar used for purposes of measuring the SLRs described above. Registry Operator agrees to not provide any differentiated treatment for the testing registrar other than no billing of the transactions. ICANN shall not use the registrar for registering domain names (or other registry objects) for itself or others, except for the purposes of verifying contractual compliance with the conditions described in this Agreement. PUBLIC INTEREST COMMITMENTS Registry Operator will use only ICANN accredited registrars that are party to the Registrar Accreditation Agreement approved by the ICANN Board of Directors on 27 June 2013 in registering domain names. A list of such registrars shall be maintained by ICANN on ICANN’s website. (Intentionally omitted. Registry Operator has not included commitments, statements of intent or business plans provided for in its application to ICANN for the TLD.) Registry Operator agrees to perform the following specific public interest commitments, which commitments shall be enforceable by ICANN and through the Public Interest Commitment Dispute Resolution Process established by ICANN (posted at xxxx://xxx.xxxxx.xxx/en/resources/registries/picdrp), which may be revised in immaterial respects by ICANN from time to time (the “PICDRP”). Registry Operator shall comply with the PICDRP. Registry Operator agrees to implement and adhere to any remedies ICANN imposes (which may include any reasonable remedy, including for the avoidance of doubt, the termination of the Registry Agreement pursuant to Section 4.3(e) of the Agreement) following a determination by any PICDRP panel and to be bound by any such determination. Registry Operator will include a provision in its Registry-Registrar Agreement that requires Registrars to include in their Registration Agreements a provision prohibiting Registered Name Holders from distributing malware, abusively operating botnets, phishing, piracy, trademark or copyright infringement, fraudulent or deceptive practices, counterfeiting or otherwise engaging in activity contrary to applicable law, and providing (consistent with applicable law and any related procedures) consequences for such activities including suspension of the domain name. Registry Operator will periodically conduct a technical analysis to assess whether domains in the TLD are being used to perpetrate security threats, such as pharming, phishing, malware, and botnets. Registry Operator will maintain statistical reports on the number of security threats identified and the actions taken as a result of the periodic security checks. Registry Operator will maintain these reports for the term of the Agreement unless a shorter period is required by law or approved by ICANN, and will provide them to ICANN upon request. Registry Operator will operate the TLD in a transparent manner consistent with general principles of openness and non-discrimination by establishing, publishing and adhering to clear registration policies.
Ongoing Performance Measures The Department intends to use performance-reporting tools in order to measure the performance of Contractor(s). These tools will include the Contractor Performance Survey (Exhibit H), to be completed by Customers on a quarterly basis. Such measures will allow the Department to better track Vendor performance through the term of the Contract(s) and ensure that Contractor(s) consistently provide quality services to the State and its Customers. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MFMP or on the Department's website).
Continuing Performance (a) The obligations under this Agreement continue until satisfied in full and do not merge with any action performed or document executed by any Party for the purposes of performance of this Agreement.
(b) Any representation in this Agreement survives the execution of any document for the purposes of, and continues after, performance of this Agreement.
(c) Any indemnity given by any Party under this Agreement:
(i) constitutes a liability of that Party separate and independent from any other liability of that Party under this Agreement or any other agreement; and
(ii) survives and continues after performance of this Agreement.
Guarantee of Performance Parent hereby guarantees the performance by Acquisition and, after the Effective Time, the Surviving Corporation of its obligations under this Agreement, including but not limited to the Surviving Corporation's obligations under Section 5.13.
Prohibition of Performance Requirements 1. The provisions of the Agreement on Trade-Related Investment Measures in Annex 1A to the WTO Agreement (TRIMs), which are not specifically mentioned in or modified by this Agreement, shall apply, mutatis mutandis, to this Agreement.
2. Member States shall undertake joint assessment on performance requirements no later than 2 years from the date of entry into force of this Agreement. The aim of such assessment shall include reviewing existing performance requirements and considering the need for additional commitments under this Article.
