Approval and Completion If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
City Approval All labor, materials, tools, equipment, and services shall be furnished and work performed and completed subject to the approval of City or its authorized representatives, and the quality of the workmanship shall be guaranteed for one year from date of acceptance.
Authorization, Approval, etc No authorization, approval, or other action by, and no notice to or filing with, any governmental authority, regulatory body or any other Person is required either
(a) for the pledge by the Pledgor of any Collateral pursuant to this Pledge Agreement or for the execution, delivery, and performance of this Pledge Agreement by the Pledgor, or
(b) for the exercise by the Collateral Agent of the voting or other rights provided for in this Pledge Agreement, or, except with respect to any Pledged Shares, as may be required in connection with a disposition of such Pledged Shares by laws affecting the offering and sale of securities generally, the remedies in respect of the Collateral pursuant to this Pledge Agreement.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Approval of Listing At the Closing Time, the Securities shall have been approved for listing on the New York Stock Exchange, subject only to official notice of issuance.
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Corporate Approval This Agreement has been approved by the Board, and has been duly executed and delivered by Employee and on behalf of the Company by its duly authorized representative.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Legal and Regulatory Compliance
4.22.1 During the term of this Contract, Contractor must comply with all local, state, and federal licensing, accreditation and registration requirements/standards, necessary for the performance of this Contract and all other applicable federal, state and local laws, rules, and regulations.
4.22.2 While on the HCA premises, Contractor must comply with HCA operations and process standards and policies (e.g., ethics, Internet / email usage, data, network and building security, harassment, as applicable). HCA will make an electronic copy of all such policies available to Contractor.
4.22.3 Failure to comply with any provisions of this section may result in Contract termination.
State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.
