Approval of Extension Sample Clauses

Approval of Extension. Within ten (10) days after Administrative Agent's notice to Borrower that all (or some, as applicable) of Lenders have approved an Extension Request (whether pursuant to Section 2.21(a), (b) or (c)), Borrower shall pay to Administrative Agent for the account of each Lender approving the extension and each Replacement Lender an extension fee in the amount provided in the Extension Request.
Sample 1Sample 2See All (8)
AutoNDA by SimpleDocs
Approval of Extension. Within ten (10) days after the Administrative Agent's notice to the Borrower that all (or some, as applicable) of Lenders have approved an Extension Request (whether pursuant to Section 2.17(a), (b) or (c)), the Borrower shall pay to the Administrative Agent for the account of each Lender approving the extension and each Replacement Lender an extension fee in the amount provided in the Extension Request.
Sample 1
Approval of Extension. If an Extension Event occurs and the SCSA does not make a request under Clause 20.5(a) or, having made such a request, does not issue an Acceptance Notice under Clause 20.5(c) and either: (a) the SCSA determines in accordance with Clause 20.4(a) or (c) that the Scheduled Date for Practical Completion of the Principal Works, the Scheduled Date for Practical Completion of the Slab Construction Works, the Scheduled Date for Financial Completion and/or the Scheduled Date for Final Completion (as applicable) should be extended; or (b) the Independent Reviewer determines in accordance with Clause 20.10 that the Scheduled Date for Practical Completion of the Principal Works, the Scheduled Date for Practical Completion of the Slab Construction Works, the Scheduled Date for Financial Completion and/or the Scheduled Date for Final Completion (as applicable) should be extended, then the Concessionaire will, subject to Clause 20.7, be entitled to an extension and: (c) the Scheduled Date for Practical Completion of the Principal Works, the Scheduled Date for Practical Completion of the Slab Construction Works, the Scheduled Date for Financial Completion and/or the Scheduled Date for Final Completion (as applicable) will be extended as determined by the SCSA pursuant to Clause 20.4(a) or (c) or as determined by the Independent Reviewer pursuant to Clause 20.10 (as the case may be); and (d) the Approved Interchange Facility Works Program will be revised to incorporate the changes referred to in paragraph (c) and the Concessionaire must update the Approved Interchange Facility Works Program accordingly and: (i) promptly provide an updated Revised Interchange Facility Works Program to the SCSA and upon receipt by the SCSA of that Revised Interchange Facility Works Program it will become the Approved Interchange Facility Works Program; and (ii) undertake the Interchange Facility Works in accordance with the Revised Interchange Facility Works Program provided in accordance with paragraph (d)(i). (e) If an extension of time is granted in respect of the Scheduled Date for Practical Completion of the Principal Works then the Scheduled Date for Financial Completion will be extended for an equivalent period.
Sample 1

Related to Approval of Extension

  • Approval of Agreement The Board of Directors of the Company has authorized the execution and delivery of this Agreement by the Company and has approved this Agreement and the transactions contemplated hereby.

  • Waiver of Notice; Approval of Meeting; Approval of Minutes The transactions of any meeting of Limited Partners, however called and noticed, and whenever held, shall be as valid as if it had occurred at a meeting duly held after regular call and notice, if a quorum is present either in person or by proxy. Attendance of a Limited Partner at a meeting shall constitute a waiver of notice of the meeting, except when the Limited Partner attends the meeting for the express purpose of objecting, at the beginning of the meeting, to the transaction of any business because the meeting is not lawfully called or convened; and except that attendance at a meeting is not a waiver of any right to disapprove the consideration of matters required to be included in the notice of the meeting, but not so included, if the disapproval is expressly made at the meeting.

  • Approval of Listing At the Closing Time, the Securities shall have been approved for listing on the New York Stock Exchange, subject only to official notice of issuance.

  • Waiver of Notice; Approval of Meeting Whenever notice to the Members is required to be given under this Agreement, a written waiver, signed by the Person entitled to notice, whether before or after the time stated therein, shall be deemed equivalent to notice. Attendance of a Person at any such meeting of the Members shall constitute a waiver of notice of such meeting, except when the Person attends a meeting for the express purpose of objecting, at the beginning of the meeting, to the transaction of any business because the meeting is not lawfully called or convened. Neither the business to be transacted at, nor the purpose of, any regular or special meeting of the Members need be specified in any written waiver of notice unless so required by resolution of the Board. All waivers and approvals shall be filed with the Company records or made part of the minutes of the meeting.

  • Approval of Plan Approval of the Plan by the Commissioner of Internal Revenue as referred to in 17.1 means a continuing approval sufficient to establish that the Plan and related trust(s) are at all times qualified and exempt from income tax under Section 401(a) and other applicable provisions of the Internal Revenue Code of 1986, and that contributions made by the Company under the Plan are deductible for income tax purposes in accordance with law. The cognizant governmental authorities referred to in 17.1 include, without limitation, the Department of Labor, the Pension Benefit Guaranty Corporation and the Securities and Exchange Commission, and their approval means their confirmation with respect to any matter within their regulatory authority that the Plan does not conflict with applicable law.

  • PRELIMINARY APPROVAL OF SETTLEMENT Promptly upon execution of this Stipulation, Lead Plaintiffs will move for preliminary approval of the Settlement, certification of the Settlement Class for settlement purposes only, and the scheduling of a hearing for consideration of final approval of the Settlement, which motion shall be unopposed by Defendants. Concurrently with the motion for preliminary approval, Lead Plaintiffs shall apply to the Court for, and Defendants shall agree to, entry of the Preliminary Approval Order, substantially in the form attached hereto as Exhibit A.

  • PROCEDURE FOR APPROVAL OF SETTLEMENT Acceptance of this Settlement Agreement shall be sought at a hearing of the Central Regional Council of the MFDA on a date agreed to by counsel for Staff and the Respondent.

  • State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.

  • Renewal of Agreement This agreement does not automatically renew, and residence in UCF DHRL residence facilities during one agreement period does not guarantee that residence accommodations will be offered to the Student for any following periods. The Student is solely responsible for the timely completion of housing agreements for future periods. UCF DHRL housing agreements shall not be re-offered to residents who are unwilling to adhere to the basic elements of good housekeeping, and community living. UCF DHRL housing agreements shall not be re-offered to residents who disregard or violate rules, regulations, or policies established for governing UCF DHRL residential facilities. Finally, housing agreements shall not be re-offered to residents who have outstanding charges from UCF DHRL.

  • Effect of non-approval of proposals Notwithstanding that under subclause (1) any proposals of the Company are approved by the Minister or determined by arbitration award, unless each and every such proposal and matter is so approved or determined by 31 October 1992 or by such extended date or period if any as the Company shall be granted pursuant to the provisions of this Agreement then the Minister may give to the Company 12 months notice of intention to determine this Agreement and unless before the expiration of the said 12 months period all the detailed proposals and matters are so approved or determined this Agreement shall cease and determine subject however to the provisions of Clause 35.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!