Political Event A Political Event shall mean one or more of the following acts or events by or on account of any Government Instrumentality:
(a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 37 and its effect, in financial terms, exceeds the sum specified in Clause 37.1;
(b) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Concessionaire or of the Contractors;
(c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Concessionaire or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit;
(d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
(e) any event or circumstance of a nature analogous to any of the foregoing.
Non-Political Event A Non-Political Event shall mean one or more of the following acts or events:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor;
(e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority;
(f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or
(g) any event or circumstances of a nature analogous to any of the foregoing.
Environmental Events The Borrower will, and will cause BPI to, promptly give notice in writing to the Agent (i) upon Borrower’s or BPI’s obtaining knowledge of any material violation (as determined by the Borrower or BPI in the exercise of its reasonable discretion) of any Environmental Law regarding any Real Estate Asset or Borrower’s or BPI’s operations, (ii) upon Borrower’s or BPI’s obtaining knowledge of any known Release of any Hazardous Substance at, from, or into any Real Estate Asset which it reports in writing or is reportable by it in writing to any governmental authority and which is material in amount or nature or which could materially affect the value of such Real Estate Asset, (iii) upon Borrower’s or BPI’s receipt of any notice of material violation of any Environmental Laws or of any material Release of Hazardous Substances in violation of any Environmental Laws, including a notice or claim of liability or potential responsibility from any third party (including without limitation any federal, state or local governmental officials) and including notice of any formal inquiry, proceeding, demand, investigation or other action with regard to (A) Borrower’s or BPI’s or any other Person’s operation of any Real Estate Asset, (B) contamination on, from or into any Real Estate Asset, or (C) investigation or remediation of off-site locations at which Borrower or BPI or any of its predecessors are alleged to have directly or indirectly disposed of Hazardous Substances, or (iv) upon Borrower’s or BPI’s obtaining knowledge that any expense or loss has been incurred by such governmental authority in connection with the assessment, containment, removal or remediation of any Hazardous Substances with respect to which Borrower or BPI or any Partially-Owned Real Estate Entity may be liable or for which a lien may be imposed on any Real Estate Asset; any of which events described in clauses (i) through (iv) above would have a material adverse effect on the business, assets or financial condition of the Borrower and its Subsidiaries, taken as a whole. As of the date hereof, the Borrower has notified the Agent of the matters referenced on Schedule 8.5(b), to the extent such matters are disclosed in the Form 10-K referred to therein.
Material Events any other event occurs or circumstance arises which, in the opinion of the Agent (following consultation with the Banks), is likely materially and adversely to affect either (i) the ability of any Security Party to perform all or any of its obligations under or otherwise to comply with the terms of any of the Security Documents or (ii) the security created by any of the Security Documents; or
Indirect Political Event An Indirect Political Event shall mean one or more of the following acts or events:
(a) an act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or military action, civil commotion or politically motivated sabotage;
(b) industry-wide or State-wide strikes or industrial action for a continuous period of 24 (twenty four) hours and exceeding an aggregate period of 7 (seven) days in an Accounting Year;
(c) any civil commotion, boycott or political agitation which prevents collection of Fee by the Concessionaire for an aggregate period exceeding 7 (seven) days in an Accounting Year;
(d) any failure or delay of a Contractor to the extent caused by any Indirect Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(e) any Indirect Political Event that causes a Non-Political Event; or
(f) any event or circumstances of a nature analogous to any of the foregoing.
Control of Other Party’s Business Nothing contained in this Agreement shall give the Company, directly or indirectly, the right to control or direct Parent's operations prior to the Effective Time. Nothing contained in this Agreement shall give Parent, directly or indirectly, the right to control or direct the Company's operations prior to the Effective Time. Prior to the Effective Time, each of the Company and Parent shall exercise, consistent with the terms and conditions of this Agreement, complete control and supervision over its respective operations.
Special Events For the purposes of this Agreement, “special events” are defined as:
Events If either Party hereto is at any time either during this Agreement or thereafter prevented or delayed in complying with any provisions of this Agreement by reason of strikes, walk-outs, labour shortages, power shortages, fires, wars, acts of God, earthquakes, storms, floods, explosions, accidents, protests or demonstrations by environmental lobbyists or native rights groups, delays in transportation, breakdown of machinery, inability to obtain necessary materials in the open market, unavailability of equipment, governmental regulations restricting normal operations, shipping delays or any other reason or reasons beyond the control of that Party, then the time limited for the performance by that Party of its respective obligations hereunder shall be extended by a period of time equal in length to the period of each such prevention or delay.
Subsequent Developments After the date of this Contract and until the Closing Date, Seller shall use best efforts to keep Buyer fully informed of all subsequent developments of which Seller has knowledge (“Subsequent Developments”) which would cause any of Seller’s representations or warranties contained in this Contract to be no longer accurate in any material respect.
Material Changes; Undisclosed Events, Liabilities or Developments Since the date of the latest audited financial statements included within the SEC Reports, except as set forth on Schedule 3.1(i), (i) there has been no event, occurrence or development that has had or that could reasonably be expected to result in a Material Adverse Effect, (ii) the Company has not incurred any liabilities (contingent or otherwise) other than (A) trade payables and accrued expenses incurred in the ordinary course of business consistent with past practice and (B) liabilities not required to be reflected in the Company’s financial statements pursuant to GAAP or disclosed in filings made with the Commission, (iii) the Company has not altered its method of accounting, (iv) the Company has not declared or made any dividend or distribution of cash or other property to its stockholders or purchased, redeemed or made any agreements to purchase or redeem any shares of its capital stock and (v) the Company has not issued any equity securities to any officer, director or Affiliate, except pursuant to existing Company stock option plans. The Company does not have pending before the Commission any request for confidential treatment of information. Except for the issuance of the Securities contemplated by this Agreement or as set forth on Schedule 3.1(i), no event, liability, fact, circumstance, occurrence or development has occurred or exists or is reasonably expected to occur or exist with respect to the Company or its Subsidiaries or their respective businesses, prospects, properties, operations, assets or financial condition that would be required to be disclosed by the Company under applicable securities laws at the time this representation is made or deemed made that has not been publicly disclosed at least 1 Trading Day prior to the date that this representation is made.
