Service Levels Annex 1 to this Part A of this Call Off Schedule sets out the Service Levels the performance of which the Parties have agreed to measure. The Supplier shall monitor its performance of this Call Off Contract by reference to the relevant performance criteria for achieving the Service Levels shown in Annex 1 to this Part A of this Call Off Schedule (the Service Level Performance Criteria) and shall send the Customer a Performance Monitoring Report detailing the level of service which was achieved in accordance with the provisions of Part B (Performance Monitoring) of this Call Off Schedule. The Supplier shall, at all times, provide the Services in such a manner that the Service Levels Performance Measures are achieved. If the level of performance of the Supplier of any element of the provision by it of the Services during the Call Off Contract Period: is likely to or fails to meet any Service Level Performance Measure or is likely to cause or causes a Critical Service Failure to occur, the Supplier shall immediately notify the Customer in writing and the Customer, in its absolute discretion and without prejudice to any other of its rights howsoever arising including under Clause 12 of this Call Off Contract (Service Levels and Service Credits), may: require the Supplier to immediately take all remedial action that is reasonable to mitigate the impact on the Customer and to rectify or prevent a Service Level Failure or Critical Service Level Failure from taking place or recurring; and if the action taken under paragraph (a) above has not already prevented or remedied the Service Level Failure or Critical Service Level Failure, the Customer shall be entitled to instruct the Supplier to comply with the Rectification Plan Process; or if a Service Level Failure has occurred, deduct from the Call Off Contract Charges the applicable Service Level Credits payable by the Supplier to the Customer in accordance with the calculation formula set out in Annex 1 of this Part A of this Call Off Schedule; or if a Critical Service Level Failure has occurred, exercise its right to Compensation for Critical Service Level Failure in accordance with Clause 13 of this Call Off Contract (Critical Service Level Failure) (including subject, for the avoidance of doubt, the proviso in Clause 13.1.2 of this Call Off Contract in relation to Material Breach). Approval and implementation by the Customer of any Rectification Plan shall not relieve the Supplier of any continuing responsibility to achieve the Service Levels, or remedy any failure to do so, and no estoppels or waiver shall arise from any such Approval and/or implementation by the Customer. SERVICE CREDITS Annex 1 to this Part A of this Call Off Schedule sets out the formula used to calculate a Service Credit payable to the Customer as a result of a Service Level Failure in a given service period which, for the purpose of this Call Off Schedule, shall be a recurrent period of [one Month] during the Call Off Contract Period (the Service Period).
Service Level In the event that League InfoSight discovers or is notified by you of the existence of Non-Scheduled Downtime, we will use commercially reasonable efforts to determine the source of the problem and attempt to resolve it as quickly as possible.
Service Level Expectations Without limiting any other requirements of the Agreement, the Service Provider shall meet or exceed the following standards, policies, and guidelines:
Additional RO Review Criteria (1) In addition to the requirements in Subparagraph 34A, the RO must:
Criteria for Performance Assessment A. A teacher’s performance shall be assessed based on the criteria set forth in the evaluation instrument, Appendix D.
Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).
CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.
Criminal History Category With regard to determining defendant’s criminal history points and criminal history category, based on the facts now known to the government, defendant’s criminal history points equal zero and defendant’s criminal history category is I.
ADDITIONAL CONTRACTOR RESPONSIBILITIES 13 In addition to providing the services described in Paragraph 5 of this 14 Exhibit A, CONTRACTOR agrees to:
PROJECT MILESTONES, REPORTING AND PAYMENTS 15. The milestones for the projects, their relationship to the outputs, expected completion dates, relevant reporting dates and expected payments to be made are set out in bilateral schedules to this Agreement. The Commonwealth will make payments subject to the performance reports demonstrating the relevant milestone has been met.
