Attorney Review of Application and Contract Sample Clauses

Attorney Review of Application and Contract. I have been given a sufficient opportunity to review this Application and Contract and its attachments, including the Supplemental Fact Sheet (Attachment A); Medical Information Form (Attachment B); the Scholarship Rules and Regulations (Attachment C). I have also had the opportunity to consult with an attorney of my own choosing to give me legal advice with regard to this Application and Contract. I understand that this Application and Contract is a legal document and that if I
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Attorney Review of Application and Contract. I have been given a sufficient opportunity to review this Application and Contract and its attachments, including the Supplemental Fact Sheet (Attachment A); Emergency Information (Attachment B), Medical Responsibility Form (Attachment C); Scholarship Rules and Regulations (Attachment D) Social Media Policy (Attachment E), and Coaching Disclosure Form (Attachment F). I have also had the opportunity to consult with an attorney of my own choosing to give me legal advice with regard to this Application and Contract. I understand that this Application and Contract is a legal document and that if I sign and submit it to the State or Local Organization and it is accepted, I have agreed to be bound by this Application and Contract and its attachments.
Sample 1Sample 2Sample 3See All (6)
Attorney Review of Application and Contract. I have been given a sufficient opportunity to review this Application and Contract and its attachments, including the Supplemental Fact Sheet (Attachment A); Medical Information Form (Attachment B); the Scholarship Rules and Regulations (Attachment C). I have also had the opportunity to consult with an attorney of my own choosing to give me legal advice with regard to this Application and Contract. ( ) I have consulted an attorney about this Application and Contract or ( ) I have decided that I do not need to do so (check applicable choice). I understand that this Application and Contract is a legal document and that if I sign and submit it to the Miss Outstanding Teen Organization and it is accepted, it will create legal obligations that will be binding on me. I agree to be bound by this Application and Contract and its attachments.
Sample 1
Attorney Review of Application and Contract. I have been given a sufficient opportunity to review this Application and Contract and its attachments, including the
Sample 1
Attorney Review of Application and Contract. I have been given a sufficient opportunity to review this Application and Contract and its attachments, including the Supplemental Fact Sheet (Attachment A); Medical Information Form (Attachment B); the Scholarship Rules and Regulations (Attachment C). I have also had the opportunity to consult with an attorney of my own choosing to give me legal advice with regard to this Application and Contract. I understand that this Application and Contract is a legal document and that if I sign and submit it to the Miss Minnesota Organization and it is accepted, I have agreed to be bound by this Application and Contract and its attachments.
Sample 1

Related to Attorney Review of Application and Contract

  • Search, Enquiry, Investigation, Examination And Verification a. The Property is sold on an “as is where is basis” subject to all the necessary inspection, search (including but not limited to the status of title), enquiry (including but not limited to the terms of consent to transfer and/or assignment and outstanding charges), investigation, examination and verification of which the Purchaser is already advised to conduct prior to the auction and which the Purchaser warrants to the Assignee has been conducted by the Purchaser’s independent legal advisors at the time of execution of the Memorandum. b. The intending bidder or the Purchaser is responsible at own costs and expenses to make and shall be deemed to have carried out own search, enquiry, investigation, examination and verification on all liabilities and encumbrances affecting the Property, the title particulars as well as the accuracy and correctness of the particulars and information provided. c. The Purchaser shall be deemed to purchase the Property in all respects subject thereto and shall also be deemed to have full knowledge of the state and condition of the Property regardless of whether or not the said search, enquiry, investigation, examination and verification have been conducted. d. The Purchaser shall be deemed to have read, understood and accepted these Conditions of Sale prior to the auction and to have knowledge of all matters which would have been disclosed thereby and the Purchaser expressly warrants to the Assignee that the Purchaser has sought independent legal advice on all matters pertaining to this sale and has been advised by his/her/its independent legal advisor of the effect of all the Conditions of Sale. e. Neither the Assignee nor the Auctioneer shall be required or bound to inform the Purchaser of any such matters whether known to them or not and the Purchaser shall raise no enquiry, requisition or objection thereon or thereto.

  • Attorney Review The Purchaser acknowledges that Purchaser has had the opportunity to consult with its legal counsel regarding the Agreement and that accordingly the terms of the Agreement are not to be construed against any party because that party drafted the Agreement or construed in favor of any Party because that Party failed to understand the legal effect of the provisions of the Agreement.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • Scope of Application Except as otherwise provided in this Agreement, the dispute settlement provisions of this Chapter shall apply with respect to the settlement of all disputes between the Parties regarding the interpretation or application of this Agreement, whenever a Party considers that the other Party has failed to carry out its obligations under this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • ADB’s Review of Procurement Decisions 11. All contracts procured under international competitive bidding procedures and contracts for consulting services shall be subject to prior review by ADB, unless otherwise agreed between the Borrower and ADB and set forth in the Procurement Plan.

  • Examination and Review (i) After receipt of the Closing Working Capital Statement, Seller will have *** (***) days from the date on which Buyer has provided to Seller all access and information reasonably requested for such purposes (the “Review Period”) to review the Closing Working Capital Statement. During the Review Period, Seller and its accountants will have full access to the relevant books and records of Buyer, the personnel of, and work papers prepared by, Buyer and/or Buyer’s accountants to the extent that they relate to the Closing Working Capital Statement and to such historical financial information (to the extent in Buyer’s possession) relating to the Closing Working Capital Statement as Seller may reasonably request for the purpose of reviewing the Closing Working Capital Statement and to prepare a Statement of Objections. (ii) On or prior to the last day of the Review Period, Seller may object to the Closing Working Capital Statement by delivering to Buyer a written statement setting forth Seller’s objections in reasonable detail, indicating each disputed item or amount and the basis for Seller’s disagreement therewith (the “Statement of Objections”). If Seller fails to deliver the Statement of Objections before the expiration of the Review Period, then the Closing Working Capital Statement and the Post-Closing Adjustment, as the case may be, reflected in the Closing Working Capital Statement will be deemed to have been accepted by Seller. If Seller delivers the Statement of Objections before the expiration of the Review Period, Buyer and Seller will negotiate in good faith to resolve such objections within *** (***) days after the delivery of the Statement of Objections (the “Resolution Period”), and, if the same are so resolved within the Resolution Period, then the Post-Closing Adjustment and the Closing Working Capital Statement with such changes as may have been previously agreed in writing by Buyer and Seller, will be final and binding.

  • Completion of Review for Certain Review Receivables Following the delivery of the list of the Review Receivables and before the delivery of the Review Report by the Asset Representations Reviewer, the Servicer may notify the Asset Representations Reviewer if a Review Receivable is paid in full by the Obligor or purchased from the Issuer in accordance with the terms of the Basic Documents. On receipt of such notice, the Asset Representations Reviewer will immediately terminate all Tests of the related Review Receivable, and the Review of such Review Receivables will be considered complete (a “Test Complete”). In this case, the related Review Report will indicate a Test Complete for such Review Receivable and the related reason.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!