Rent Abatement Except for the negligence or willful act of Tenant or its agents, employees, contractors or invitees, if all or any part of the Premises are rendered untenantable by fire or other casualty and this Lease is not terminated, Monthly Base Rent and Rent Adjustments shall xxxxx for that part of the Premises which is untenantable on a per diem basis from the date of the casualty until Landlord has Substantially Completed the repair and restoration work in the Premises which it is required to perform, provided, that as a result of such casualty, Tenant does not occupy the portion of the Premises which is untenantable during such period.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.
Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.
Base Rent Lessee shall pay Base Rent and other rent or charges, as the same may be adjusted from time to time, to Lessor in lawful money of the United States, without offset or deduction, on or before the day on which it is due under the terms of this Lease. Base Rent and all other rent and charges for any period during the term hereof which is for less than one full month shall be prorated based upon the actual number of days of the month involved. Payment of Base Rent and other charges shall be made to Lessor at its address stated herein or to such other persons or at such other addresses as Lessor may from time to time designate in writing to Lessee.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
