Site Safety Supervisor 62.1 On every job site, where the Employer is the principal contractor it shall appoint a management representative responsible for safety (Site Safety Supervisor). The Employer will ensure the Site Safety Supervisor has the necessary authority to ensure that all safety laws, procedures or Codes of Practice are observed, and that the following Safety Agreement is applied.
62.2 The Employer when appointing the person appointed as the Site Safety Supervisor must ensure that person has and maintainsthe appropriate experience and knowledge of the safety requirements of the work being performed. Other duties may be assigned by the Employer to a Site Safety Supervisor, provided that such duties shall not prevent him/her from exercising their duties as a Site Safety Supervisor.
Building Signage 1. Tenant shall be entitled to the greater of: (i) one (1) exclusive tenant identification sign per Building that does not to exceed 75 square feet, or (ii) Tenant’s pro rata share of the maximum exterior signage permitted by applicable Laws that is allocated to the parcel on which the Building is located (the “Building Signage”). The exact location of the Building Signage shall be determined by Tenant, subject to all applicable Laws, any reasonable signage guidelines for the Project established by Landlord that are provided to Tenant prior to installation of the Building Signage, and Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such right to the Building Signage is personal to Tenant and is subject to the following terms and conditions: (a) Tenant shall submit plans and drawings for the Building Signage to Landlord and to the City of San Mateo and to any other public authorities having jurisdiction and shall obtain written approval from Landlord (not to be unreasonably withheld, conditioned or delayed) and, if applicable, each such jurisdiction prior to installation, and shall comply with all applicable Laws; (b) Tenant shall, at Tenant’s sole cost and expense, design, construct and install the Building Signage; (c) the size, color and design of the Building Signage shall be subject to Landlord’s prior written approval; and (d) Tenant shall maintain the Building Signage in good condition and repair, and all costs of maintenance and repair shall be borne by Tenant. Maintenance shall include, without limitation, cleaning and, if the Building Signage is illuminated, relamping at reasonable intervals. Tenant shall be responsible for any electrical energy used in connection with the Building Signage. Notwithstanding the foregoing, Tenant shall not be liable for any fee in connection with Tenant’s right to display the Building Signage in accordance with this Lease. At Landlord’s option, Tenant’s right to the Building Signage may be revoked and terminated upon occurrence of any of the following events: (i) Tenant shall be in default under this Lease beyond any applicable notice and cure periods; (ii) Tenant leases or occupies less than 75% of the Premises, or (iii) this Lease shall terminate or otherwise no longer be in effect.
2. Upon the expiration or earlier termination of this Lease or at such other time that Tenant’s signage rights are terminated pursuant to the terms hereof, if Tenant fails to remove the Building Signage and repair the Building in accordance with the terms of this Lease, Landlord shall cause the Building Signage to be removed from the Building and the Building to be repaired and restored to the condition which existed prior to the installation of the Building Signage (including, if necessary, the replacement of any precast concrete panels), all at the sole cost and expense of Tenant and otherwise in accordance with this Lease, without further notice from Landlord notwithstanding anything to the contrary contained in this Lease. Tenant shall pay all costs and expenses for such removal and restoration within fifteen (15) business days following delivery of an invoice therefor accompanied by reasonable supporting documentation. The rights provided in this Section 36.A shall be non-transferable (except with respect to a Permitted Transferee) unless otherwise agreed by Landlord in writing in its sole discretion.
Building With respect to each parcel of Real Estate, all of the buildings, structures and improvements now or hereafter located thereon. Business Day. Any day on which banking institutions located in the same city and State as the Agent’s Head Office are located are open for the transaction of banking business and, in the case of LIBOR Rate Loans, which also is a LIBOR Business Day.
Building Services Labor Law Article 9 applies to Contracts for building service work over $1,500 with a public agency, that: (i) involve the care or maintenance of an existing building, or (ii) involve the transportation of office furniture or equipment to or from such building, or (iii) involve the transportation and delivery of fossil fuel to such building, and (iv) the principal purpose of which is to furnish services through use of building service employees.
Supervisors Working (a) The Employer agrees that the function of supervisors is the supervision of Employees and not the performance of the work of the employees they supervise. Accordingly, the Employer agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform any bargaining unit work, except to train employees or demonstrate safety, or as otherwise provided in the applicable Supplement, Rider or Addendum. However, in the case of Acts of God, supervisors shall comply with the procedures in subsections (b) and (c) and may only perform bargaining unit work until bargaining unit employees are available. The Employer shall make every reasonable effort to maintain a sufficient workforce to staff its operations with bargaining unit employees. The Employer also agrees that supervisors or other employees of the Employer who are not members of the bargaining unit shall not perform bargaining unit work in preparing the work areas before the start of the Employer’s hub, preload or reload operation, nor shall the Employer send any bargaining unit employee home and then have such employee’s work performed by a supervisor or other employees of the Employer who are not a member of the bargaining unit.
(b) When additional employees are necessary to complete the Employer’s operations on any shift or within any classification, the supervisor shall exhaust all established local practices to first use bargaining unit employees including where applicable, double shifting, early call-in, and overtime.
(c) If there is no established local practice, the following shall apply with regard to inside work. Within each building, each operation will maintain appropriate list(s), by seniority, of those part-time employees requesting coverage work. It will be the employees’ responsibility to sign up on the appropriate list. The Company shall post such lists and employees who are interested in adding their names to the lists shall do so on the first working day of each month. It will be the employee’s responsibility to make sure his/her their contact information is correct. Employees who are unavailable to work on three (3) separate occasions within a calendar month shall have their names removed from the coverage list. Those employees shall be eligible to re-sign the list the following month. When coverage work is available, the Company will use the appropriate list to fill the required positions, and such employees will work as assigned. The employee must be qualified for the available work and double shift employees shall have seniority among themselves. No employee is allowed to work more than two (2) shifts in any twenty-four (24) hour period. Local call verification practices and procedures shall remain in place. Nothing contained in this Section shall change existing practices or procedures covering full-time work.
(d) If it is determined at any step of the grievance and/or arbitration procedure that this Section, or a “supervisor working” provision in a Supplement, Rider or Addendum, has been violated, the aggrieved employee will be paid as follows: (i) if the actual hours worked by the supervisor amounts to two (2) hours or less, the aggrieved employee will be paid for the actual hours worked by the supervisor at the rate of double time the employee’s rate of pay at the time of the incident; or (ii) if the supervisor works more than two (2) hours, the aggrieved employee shall be paid four (4) hours at straight time or actual hours worked at double time the employee’s rate of pay at the time of the incident, whichever is greater. If no aggrieved employee can be identified, the payment will be made to the grievant. Such remedy shall be in addition to any other remedies sought by the Union in the appropriate grievance procedure. If a Supplement, Rider, or Addendum does not have a provision requiring notice to the xxxxxxx when a supervisor works the following shall be incorporated: “In the event a supervisor does perform bargaining unit work, the Employer shall notify the appropriate shop xxxxxxx as soon as possible.” In the event that any individual supervisor is found to be in violation of the first paragraph of this Subsection three (3) times in any nine (9) month rolling period, the grievance shall be paid at triple quadruple time the employee’s rate of pay for the hours specified in the first paragraph of this subsection.
WORK BY SUPERVISORS Supervisors and all other excluded employees will not work on any job for which rates are established by this agreement, except for the purpose of instruction, experimenting, safety or environ- mental reasons or when regular employees are not available.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements:
(a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work.
(b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay.
(c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord.
(d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
CONTRACTOR SUPERVISION Contractor shall provide competent supervision of personnel employed on the job Site, use of equipment, and quality of workmanship.
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
