Interim Operations Except as (x) required by applicable Law, (y) expressly contemplated or required by this Agreement or (z) set forth in Section 6.1 of the Company Disclosure Letter, the Company Parties covenant and agree that, from and after the execution and delivery of this Agreement and prior to the Company Merger Effective Time, except with the prior written consent of Parent (which consent is not to be unreasonably withheld, conditioned or delayed), each of the Company Parties shall, and shall cause their Subsidiaries to, conduct their business in the ordinary course and shall, and shall cause their Subsidiaries to, use their respective commercially reasonable efforts to (1) preserve their business organizations intact and (2) maintain existing relations and goodwill with Governmental Entities and customers, suppliers, employees and business associates.
(a) Without limiting the generality of the foregoing and in furtherance thereof, from and after the execution and delivery of this Agreement until the Company Merger Effective Time, except as (x) required by applicable Law, (y) expressly contemplated or required by this Agreement, or (z) as set forth in the relevant subsection of Section 6.1 of the Company Disclosure Letter (it being understood and hereby agreed that if any action is expressly permitted by any of the following subsections such action shall be expressly permitted under the first sentence of Section 6.1), except with the prior written consent of Parent (which consent not to be unreasonably withheld, conditioned or delayed), none of the Company Parties will and the Company Parties will not permit any of their Subsidiaries to:
(i) adopt any change in the Company's certificate of incorporation or bylaws or DPA's limited liability company agreement, or adopt any material change in the applicable governing instruments of any of their Subsidiaries;
(ii) merge or consolidate with any other Person or restructure, reorganize or completely or partially liquidate, except for (A) the Mergers or (B) any such transaction between wholly owned Subsidiaries of the Company Parties, or between any wholly owned Subsidiary of the Company Parties and the Company Parties, unless reasonably objected to by Parent following consultation;
(iii) acquire (by merger, consolidation, acquisition of stock or assets or otherwise) (x) any corporation, partnership or other business organization or (y) any assets from any other Person (excluding ordinary course purchases of goods, products and off-the-shelf Intellectual Property), except, following reasonable advanced consultation with Parent, where the consideration in such transaction is not in excess of $2,000,000 individually or $5,000,000 in the aggregate;
(iv) issue, sell, pledge, dispose of, grant, transfer, encumber, or authorize the issuance, sale, pledge, disposition, grant, transfer, or encumbrance of, any shares of its capital stock or equity interests or the capital stock or equity interests of any of its Subsidiaries (other than (A) the issuance of Class A Shares upon the exercise of Company Options and settlement of Company RSAs and Director RSAs in accordance with the Stock Plan, in each case that are outstanding as of the date hereof or that are issued after the date hereof in compliance with this Agreement, (B) the issuance of Class A Shares pursuant to that certain Exchange Agreement dated as of October 3, 2007, as amended through the date hereof, by and among the Company Parties and certain unitholders of DPA (the “Exchange Agreement”), (C) between wholly owned Subsidiaries of the Company Parties or between a wholly owned Subsidiary of the Company Parties and a Company Party), or securities convertible or exchangeable into or exercisable for any shares of such capital stock, or any options, stock units, stock awards, warrants or other rights of any kind to acquire any shares of such capital stock, equity interests, convertible or exchangeable securities;
(v) make any loans, advances or capital contributions to or investments in any Person (other than the Company Parties or any direct or indirect wholly owned Subsidiary of the Company Parties) other than in the ordinary course of business consistent with past practice (including business expense advances to employees) in amounts not in excess of $750,000;
(vi) declare, set aside, make or pay any dividend or other distribution, payable in cash, stock, property or otherwise, with respect to any of its capital stock or equity interests (except for (A) regular quarterly cash dividends at a rate not in excess of $0.09 per Class A Share and $0.09 per New Class A Unit, with record dates and payment dates consistent with the prior year, (B) tax distributions not in excess of those provided for pursuant to Section 4.4 of the limited liability company agreement of DPA or (C) dividends paid by any direct or indirect wholly owned Subsidiary to the Company Parties or to any other direct or indirect wholly owned Subsidiary) or enter into any agreement with respect to the voting of its capital stock;
(vii) reclassify, split, combine, subdivide or redeem, purchase or otherwise acquire, directly or indirectly, any of its capital stock or equity interests or securities convertible or exchangeable into or exercisable for any shares of its capital stock or equity interests (other than the acquisition in the ordinary course of business consistent with past practice of any Class A Shares tendered by current or former Service Providers in connection with the cashless exercise of Company Options or in order to pay Taxes in connection with the exercise of Company Options or the vesting of Company RSAs and Director RSAs or in connection with any obligation under the Exchange Agreement);
(viii) incur any Indebtedness for borrowed money or guarantee such Indebtedness of another Person (other than a wholly owned Subsidiary of the Company Parties), or issue or sell any debt securities or warrants or other rights to acquire any debt security of the Company Parties or any of their Subsidiaries, in each case other than (A) in the ordinary course of business consistent with past practice with a face value or principal amount not in excess of $2,500,000 in the aggregate, or (B) in the ordinary course under letters of credit, lines of credit or other credit facilities or arrangements in effect on the date hereof so long as the total Indebtedness incurred under all such letters of credit, lines of credit or credit facilities does not exceed $50,000,000 in the aggregate;
(ix) make or authorize any capital expenditures in excess of $500,000 individually or $1,500,000 in the aggregate, other than any capital expenditure (or series of related capital expenditures) consistent in all material respects with the 2013 capital expenditure budget of the Company Parties and their Subsidiaries in effect on the date of this Agreement (a copy of which has been previously provided to Parent);
(x) make any material changes with respect to any method of Tax or financial accounting policies or procedures, except as required by changes in GAAP or by a Governmental Entity;
(xi) compromise, settle or agree to settle any claims (A) involving amounts in excess of $250,000 individually or $1,000,000 in the aggregate, except to the extent reflected or reserved against in the Company's consolidated balance sheet as of September 30, 2012 included in the Company Reports in respect of the claim being settled or (B) that would impose any material non-monetary obligations on the Company Parties or their Subsidiaries or Affiliates that would continue after the Company Merger Effective Time;
(xii) make any material Tax election, file any material amended Tax Return, settle or compromise any material Tax liability, enter into any closing agreement with respect to any material Tax or surrender any right to claim a material Tax refund;
(xiii) transfer, sell, lease, license, mortgage, pledge, surrender, encumber, divest, cancel, abandon or allow to lapse or expire, xxxxx x Xxxx (other than a Permitted Lien) on or otherwise dispose of any assets, properties or rights of the Company Parties or their Subsidiaries, including capital stock of any of their Subsidiaries that are material to the Company Parties and their Subsidiaries, taken as a whole, except (A) in the ordinary course of business consistent with past practice or (B) Liens granted in connection with any indebtedness permitted under this Section 6.1;
(xiv) except as required under applicable Law or the terms of any Benefit Plan in effect as of the date hereof (A) grant, provide or increase (or commit to grant, provide or increase) any severance or termination payments or benefits to any current or former Service Provider who is or was an executive officer, a director or other Service Provider earning annual compensation (base salary and incentive opportunities) in excess of $750,000 (any such Service Provider, a “Material Service Provider”), grant or provide for (or commit to grant or provide for) any severance or termination payments or benefits to any other current or former Service Provider other than in the ordinary course of business consistent with past practice or increase (or commit to increase) any severance or termination payments or benefits; (B) increase in any manner the compensation or benefits of any current or former Service Provider, except (x) for increases in base salary in the ordinary course where the aggregate increase does not exceed 4.5% percent of the aggregate annualized salaries in 2012 and (y) the payment of bonuses for the 2012 performance year in the ordinary course of business and, with respect to Material Service Providers consistent with past practice, and otherwise in the aggregate consistent with past practice, and not in excess of the amounts set forth in Section 6.1(a)(xiv) of the Company Disclosure Letter; (D) become a party to, establish, adopt, terminate, materially amend (or commit to become a party to, establish, adopt, terminate, or materially amend) any Benefit Plan or arrangement that would have been a Benefit Plan if in effect on the date hereof (other than routine changes to welfare plans) or accelerate the vesting of, or lapse of restrictions on, any compensation for the benefit of any current or former Material Service Provider; (E) cause the funding of any rabbi trust or similar arrangement or take any action to fund or in any other way secure the payment of compensation or benefits under any Benefit Plan; or (F) terminate the employment or services of any Material Service Provider other than for cause, or hire any Person that would reasonably be expected to be a Material Service Provider;
(xv) abandon, convey title (in whole or in part), exclusively license or grant any right or other licenses to material Intellectual Property owned or exclusively licensed to the Company Parties or any of their Subsidiaries, or enter into licenses or agreements that impose material restrictions upon the Company Parties or any of their Subsidiaries with respect to its or their use of material Intellectual Property owned by any third party, in each case other than in the ordinary course of business consistent with past practice;
(A) except in the ordinary course of business consistent with past practice, (1) modify or amend, or voluntarily or prematurely terminate, any Material Contract (other than extensions at the end of term that do not materially modify or amend the terms of such Contract or modifications or amendments to reflect actual services performed), (2) enter into any successor agreement to an expiring Material Contract that materially modifies or amends the terms of such expiring Material Contract or (3) enter into any new agreement that would have been considered a Material Contract if it were entered into at or prior to the date hereof other than any such Contracts that may be cancelled, terminated or withdrawn without material liability to the Company Parties or their Subsidiaries upon notice of 90 days or less or (B) enter into any new agreement that would have been considered a Material Contract pursuant to clause (B), (I), (O) or (Q) of Section 5.1(q) if it were entered into at or prior to the date hereof;
(xvii) fail to maintain in full force and effect material insurance policies covering the Company Parties and their Subsidiaries and their respective properties, assets and businesses in a form and amount consistent with past practice; or
(xviii) agree, authorize or commit to do any of the foregoing.
(b) Each of the Buyer Parties agrees that, from and after the execution and delivery of this Agreement and until the Company Merger Effective Time, it shall not consummate or agree to consummate any purchase or other acquisition of any assets, licenses, operations, rights or businesses (other than as expressly contemplated by this Agreement) that, individually or in the aggregate with any other such purchase or acquisition, is reasonably likely to (i) prevent or materially delay from obtaining any consents, registrations, approvals, permits or authorizations required to be obtained from any Governmental Entity in connection with the consummation of the Mergers and the other transactions contemplated hereby, (ii) result in the imposition of a condition or conditions on any such consents, registrations, approvals, permits or authorizations, or (iii) otherwise prevent or materially delay any party hereto from performing its obligations hereunder or consummating the Mergers and the other transactions contemplated hereby.
(c) Nothing contained in this Agreement is intended to give any Buyer Party, directly or indirectly, the right to control or direct the Company Parties' or their Subsidiaries' operations prior to the Company Merger Effective Time, and nothing contained in this Agreement is intended to give the Company Parties or their Subsidiaries, directly or indirectly, the right to control or direct the Buyer Parties' operations. Prior to the Company Merger Effective Time, each of the Buyer Parties and the Company Parties shall exercise, consistent with the terms and conditions of this Agreement, complete control and supervision over its and its Subsidiaries' respective operations.
(d) Unless otherwise agreed by the parties hereto, following the date hereof and prior to the Closing Date, the Company shall use commercially reasonable efforts to make available to Parent:
(i) an estimate of the amounts potentially payable to each Service Provider under any Benefit Plan in connection with the execution and delivery of this Agreement, the adoption of this Agreement by holders of shares constituting the Company Requisite Vote or the consummation of the transactions contemplated hereby (either alone or in conjunction with any other event, including as a result of a termination of employment or service), including the amount of any “excess parachute payments” within the meaning of Section 280G of the Code and any excise tax gross-up that could become payable under any Benefit Plans;
(ii) complete and correct copies of each Lease; and
(iii) true and complete current copies of all material Benefit Plans and, where applicable, (A) the most recently prepared actuarial report or financial statement with respect thereto, (B) the most recent summary plan description, and all material modifications thereto with respect thereto, (C) the most recent annual report (Form 5500 Series) and accompanying schedule with respect thereto, (D) the most recent determination letter with respect thereto, (E) copies of any material written correspondence with a Governmental Entity with respect thereto and (F) any related funding arrangements with respect thereto.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
