Change Order Directive Process
Change Order Directive Process Sample Clauses
Related to Change Order Directive Process
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.
Construction Change Directives 1.1.1, 3.4.2, 3.11, 3.12.8, 4.2.8, 7.1.1, 7.1.2, 7.1.3, 7.3, 9.3.1.1 Construction Schedules, Contractor’s 3.10, 3.11, 3.12.1, 3.12.2, 6.1.3, 15.1.6.2
Grievance Process (a) Either party, with the agreement of the other party, may submit a grievance to Grievance Mediation at any time within ten (10) working days after the Employer’s decision has been rendered at the step prior to arbitration. Where the matter is so referred, the mediation process shall take place before the matter is referred to Arbitrator. (b) Grievance Mediation shall be scheduled within twenty (20) working days of the grievance being submitted to mediation, or longer period as agreed by the parties. (c) No matter may be submitted to Grievance Mediation which has not been properly carried through the grievance procedure, provided that the parties may extend the time limits fixed in the grievance procedure. (d) The parties shall agree on a mediator. (e) Proceedings before the Mediator shall be informal. Accordingly, the rules of evidence will not apply, no record of the proceedings shall be made and legal counsel shall not be used by either party, unless otherwise mutually agreed. (f) If possible, an agreed statement of facts will be provided to the Mediator, and if possible, in advance of the Grievance Mediation Conference. (g) The Mediator will have the authority to meet separately with either party. (h) If no settlement is reached within five (5) working days following Grievance Mediation, the parties are free to submit the matter to Arbitration in accordance with the provisions of the collective agreement. In the event that a grievance which has been mediated subsequently proceeds to arbitration, no person serving as the Mediator may serve as an Arbitrator, unless otherwise mutually agreed. Nothing said or done by the mediator may be referred to Arbitration. (i) The Union and Employer will share the cost of the Mediator, if any.
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Discipline Procedure 1. Disciplinary action may be imposed for violation of written rules and regulations as set forth by the Board, incompetence, inefficiency, dishonesty, drunkenness, immoral conduct, insubordination, discourteous treatment of the public, neglect of duty, misfeasance, malfeasance, nonfeasance, any other failure of good behavior, or conviction of a felony. 2. No employee shall be disciplined without first having had the opportunity for a hearing, if the employee so requests, with an OAPSE representative of his/her choice present. The employee shall be given a written statement containing the charges and the time and place of the hearing. The written statement shall notify the employee of his/her rights to OAPSE representation. The employee must be given the opportunity to sign the statement acknowledging receipt of the statement and date received. Under emergency conditions as determined by the supervisor (including, but not limited to, health and/or safety of the employee or other employees; blatant insubordination; or refusal to work), the supervisor may immediately suspend an employee without pay for a period of up to three (3) work days without the formal hearing described above. An opportunity for a formal hearing with the supervisor must be provided within the suspension period. Failure to provide an opportunity for a hearing during the suspension period shall preclude the right of further discipline for the offense causing the initial suspension. Emergency suspensions will not be subject to Section 6 of this Article. 3. Disciplinary action of less than discharge should generally be progressive and corrective in nature. A. Disciplinary actions shall be grievable. This Section shall supersede existing state law governing termination of employment (O.R.C. 3319.081). B. In determining progressive and corrective action, just cause shall be construed and limited to the nature and seriousness of the offense, the effect the alleged conduct has on the Board’s operation, the discipline or lack thereof used in other similar situations known to the Board, and the appropriateness of the proposed penalty in view of the record and length of service of the charged employee. The enumeration of these factors is not intended to preclude either the exercise of good and sound business judgment or to minimize the importance of an employee’s property interest in his job.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the
Acceptance Process All deliverables must be received and accepted in writing by Department’s Grant Manager before payment. The Grantee shall work diligently to correct all deficiencies in the deliverable that remain outstanding, within a reasonable time at Grantee’s expense. If Department’s Grant Manager does not accept the deliverables within 30 days of receipt, they will be deemed rejected.
Informal Process The Informal Process provides an Employee with the opportunity to resolve his or her concern by using the open door process, with the assistance of a FC member, within 30 calendar days of the date the Employee became aware of the issue. While an Employee may speak with anyone in the open door process regarding a concern or problem, the Employee is encouraged to take this concern up with his immediate supervisor or may request the assistance of the Employee Advocate or a FC member to facilitate resolution of the issue.
