Software Support During the Term, Seller shall use commercially reasonable efforts to provide all Software updates and qualified Software upgrades in accordance with the terms of the Service Contract as such materials become commercially available for distribution. Purchaser’s use of all Software, updates, and upgrades of Software shall be subject to this Agreement, the Original Terms, and the applicable XXXX.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").
TAX SUPPORT SERVICES BNY Mellon shall provide the following tax support services for each Fund: Provide various data and reports as agreed upon in the SLDs to support TRP’s tax reporting and tax filing obligations, including: · Wash sales reporting; · QDI reporting; · DRD reporting; · PFIC analysis; · Straddle analysis; · Paydown adjustments; · Equalization debit adjustments · Tax compliance under §851, §817(h); · Foreign bond sale analysis (§988); · Troubled debt analysis; · Estimation of income for excise tax purposes; · Swap analysis; · Inflation adjustments; · §1256 adjustments; · Market discount analysis; OID adjustments; · CPDI analysis; · Shareholder tax reporting information (e.g. FTC, UGG income, foreign source income by country, exempt income by state); Provide data, and reports based on such data, maintained by BNY Mellon on its fund accounting platform as reasonably requested by TRP to support TRP’s obligations to comply with requests from tax authorities and TRP’s tax reporting and tax filing obligations. Assist with other tax-related data needs as mutually agreed upon in writing from time-to-time.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Hosting Services 13.1 If Supplier or its subcontractor, affiliate or any other person or entity providing products or services under the Contract Hosts Customer Data in connection with an Acquisition, the provisions of Appendix 1, attached hereto and incorporated herein, apply to such Acquisition. 13.2 If the Hosting of Customer Data by Supplier or its subcontractor, affiliate or any other person or entity providing products or services under the Contract contributes to or directly causes a Data Breach, Supplier shall be responsible for the obligations set forth in Appendix 1 related to breach reporting requirements and associated costs. Likewise if such Hosting contributes to or directly causes a Security Incident, Supplier shall be responsible for the obligations set forth in Appendix 1, as applicable. 14 Change Management
Compliance Support Services Provide compliance policies and procedures related to services provided by BNY Mellon and, if mutually agreed, certain of the BNY Mellon Affiliates; summary procedures thereof; and periodic certification letters. · Such Compliance Support Services are administrative in nature and do not constitute, nor shall they be construed as constituting, legal advice or the provision of legal services for or on behalf of a Fund or any other person, and such services are subject to review and approval by the applicable Fund and by the Fund’s legal counsel. · Provide access to Fund records so as to permit the Fund or TRP to test the performance of BNY Mellon in providing the services under this Agreement. · Such Compliance Support Services performed by BNY Mellon under this Agreement shall be at the request and direction of the Fund and/or its chief compliance officer (the “Fund’s CCO”), as applicable. BNY Mellon disclaims liability to the Fund, and the Fund is solely responsible, for the selection, qualifications and performance of the Fund’s CCO and the adequacy and effectiveness of the Fund’s compliance program.
Software Updates XXXXX agrees to keep current with software licensed from Skyward and will install new versions on a timeline approved by XXXXX governance. This timeline will be communicated by NWRDC to the Districts.
Cloud Services You will not intentionally (a) interfere with other customers’ access to, or use of, the Cloud Service, or with its security; (b) facilitate the attack or disruption of the Cloud Service, including a denial of service attack, unauthorized access, penetration testing, crawling, or distribution of malware (including viruses, trojan horses, worms, time bombs, spyware, adware, and cancelbots); (c) cause an unusual spike or increase in Your use of the Cloud Service that negatively impacts the Cloud Service’s operation; or (d) submit any information that is not contemplated in the applicable Documentation.
Network Services Local Access Services In lieu of any other rates and discounts, Customer will pay fixed monthly recurring local loop charges ranging from $1,200 to $2,000 for TDM-based DS-3 Network Services Local Access Services at 2 CLLI codes mutually agreed upon by Customer and Company.
