Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
Compensation on Termination (a) If this Project Agreement is terminated pursuant to Sections 34.3(a), 35.2(a)(ii), 36.1, 36.2 or 36.3, then:
Compensation for Damages 4.1 If the Principal has disqualified the Bidder from the tender process prior to the award according to Section 3, the Principal is entitled to demand and recover the damages equivalent Xxxxxxx Money Deposit/Bid Security.
Other Compensation Unless otherwise stated, this Agreement does not include the Agent’s service of preparing the Property for sale or refinance, modernization, fire or major damage restoration, rehabilitation, financial accounting or legal advice, representation before public agencies, advising on proposed new construction, debt collection, counseling, attending any Association or Condominium meetings, and any other obligation not listed as a Service. If the Owner requests the Agent to perform services not included in this Agreement, a fee shall be agreed upon before such services are performed.
Fees and Compensation Managers and Officers may receive such compensation and fees, if any, for their services, and such reimbursement for expenses, as may be determined by resolution of the Board.
SALARIES AND COMPENSATION 47 Section 17.1. Base Pay and Merit Increases……………………………………….. 47 Section 17.2. Employee's Contribution to OPERS……………………………….… 49 Section 17.3. Salary Deductions……………………………………………………... 50 Section 17.4. Working Out of Classification.......................................................... 50 Section 17.5. Shift Differential............................................................................... 51 Section 17.6. Service Credit................................................................................. 51 Section 17.7. Adoption Assistance Program......................................................... 52 Section 17.8. Pre-Tax Dependent Care Program................................................. 53 Section 17.9. Wage Rate Adjustment.................................................................. 53 Section 17.10. Individual Classification Pay Grade Assignment Change…………… 53 ARTICLE 18 – INSURANCE…………………………………………………………. 53 Section 18.1. Health and Hospitalization, Prescription Drug, Disability, Dental and Vision Coverage…………………………………………………………………… 53 Section 18.2. Cost……………………………………………………………………... 58 Section 18.3. Life Insurance………………………………………………………….. 59 Section 18.4. Continuation of Benefits while on Unpaid Leave…………………… 60 Section 18.5. Terms of Insurance Policies to Govern……………………………... 60 Section 18.6. IRC Section 125 Plan…………………………………………………. 60 Section 18.7. Disability Leave………………………………………………………… 60 Section 18.8. Benefits Booklet……………………………………………………….. 62 Section 18.9. Training…………………………………………………………………. 62
Director Compensation Petitioner shall not compensate members of the Charter School’s Governing Board in excess of reasonable expenses incurred in connection with actual attendance at board meetings or with performance of duties associated therewith.
Compensation for Convenience Termination If City shall terminate for its convenience as herein provided, City shall compensate Consulting Engineer/Architect for all Engineering/Architectural Services satisfactorily completed to date of its receipt of the termination notice and any additional Engineering/Architectural Services requested by City to bring the Project to reasonable termination. Compensation shall not include anticipatory profit or consequential damages, neither of which will be allowed.
SALARY AND COMPENSATION ARTICLE 56
