Callout Compensation A regular employee who is called back to work outside their regular working hours shall be compensated for a minimum of three hours at overtime rates. They shall be compensated from the time they leave their home to report for duty until the time they arrive back upon proceeding directly to and from work.
Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.
Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Architect's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Architect's work.
Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.
Eligibility for Overtime Compensation (a) Overtime compensation rates for all hours worked in excess of the workday and workweek identified below shall be as follows:
Call Back Compensation (a) Call back is an occasion where an employee has been released from duty and is called back to work prior to his/her normal starting time. On such occasions, the employee’s scheduled or recognized shift shall be made available for work, except that the Agency shall not be obligated to work the employee more than twelve (12) consecutive hours and the employee may choose not to work more than twelve (12) consecutive hours, excluding meal periods, of combined call back time and regular shift time.
Lump Sum Compensation Lump sum computation refers to the method of payment under this Agreement for the professional services of the Consultant.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
BROKER COMPENSATION BROKER shall be entitled to a rental commission from all rent monies collected and shall retain any charges deemed "additional rent" or fees in the lease agreement.
Director Compensation Petitioner shall not compensate members of the Charter School’s Governing Board in excess of reasonable expenses incurred in connection with actual attendance at board meetings or with performance of duties associated therewith.
